bill of quantities

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

BLOCK A ( FOUR BEDROOM DUPLEX ) ELEMENT Nr. 1 SUBSTRUCTURE (ALL PROVISIONAL) D20: Excavation and Filling. 640

m2

40.00

25,600.00

631

m

3

575.00

362,825.00

85

m

3

575.00

48,875.00

107

m

3

220.00

23,540.00

materials arising from excavations

138

m3

180.00

24,840.00

F

150mm laterite filling in layers

86

m3

1,350.00

116,100.00

G

Filling to make up levels, thickness not exceeding 150mm, 86

m3

2,100.00

180,600.00

1,212

m2

40.00

48,480.00

1,212

m

2

55.00

66,660.00

57

m2

1,050.00

59,850.00

141

m

3

21,000.00

2,961,000.00

A

Excavate topsoil average depth not exceeding 150mm

B

Excavating trenches, width exceeding 0.3m maximum depth not exceeding 1.50m

C

Excavating pits (38nr), maximum depth not exceeding 2.00m

D

Dispose excavated materials off site, in spoil heap away from site

E

Filling to excavations, thickness exceeding 250mm,

hardcore materials obtained off site H

Level and compact bottom of excavation

J

Dieldrex or other equal and approved antitermite treatment solution spread to faces of excavations E10: In situ concrete Plain in situ concrete (1:10)-40mm aggregate

K

Blinding beds, thickness not exceeding 50mm Plain in situ concrete (1:3:6)-20mm aggregate

L

Foundations Reinforced in situ concrete (1:2:4)-19mm aggregate

M

Beds/ attached steps (150mm thick)

92

m3

38,000.00

3,496,000.00

N

Column bases

26

m3

38,000.00

988,000.00

P

Column (62nos)

4

m3

38,000.00

152,000.00

Q

Circular Column 450mm Diameter (2nos) Carried to collection

1

m3

38,000.00

38,000.00 8,592,370.00

4 BEDROOM DUPLEX 1

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

E20: Formwork for in situ concrete Plain vertical sawn formwork A

Edges of beds, height not exceeding 250mm

22

m2

1,450.00

31,900.00

B

Sides of column

71

m

2

1,450.00

102,950.00

C

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight 20mm Diameter

1.260

t

240,000.00

302,400.00

D

16mm Diameter

0.390

t

240,000.00

93,600.00

E

12mm Diameter

0.550

t

240,000.00

132,000.00

0.460

t

240,000.00

110,400.00

669

m2

850.00

568,650.00

845

m2

3,800.00

3,211,000.00

Mild steel bars to BS 4449, bent. F

10mm Diameter Fabric mesh A192 weighting 42kg/m2 laid as detailed in manufacturer's manual

G

Ground floor bed/Attached ramp F10: Brick/Block walling Sandcrete blockwork in stretcher bond bedded in cement and sand mortar mix (1:6) flush pointed, filled solid with lean concrete

H

Walls, 230mm thick vertical

EXTERNAL RENDERING J

15mm thick cement and sand (1:4) smooth rendering to face of the wall

53

m2

650.00

34,450.00

53

m2

1,200.00

63,600.00

PAINTING AND DECORATION K

Prepare prime and apply one undercoat and two finishing coats of high quality "DULUX" emulsion paint on rendered wall (rate including floating)

Carried to collection

4,650,950.00

4 BEDROOM DUPLEX 2

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Collection

Page 01

8,592,370.00

Page 02

4,650,950.00

SUBSTRUCTURE CARRIED TO SUMMARY

13,243,320.00

4 BEDROOM DUPLEX 3

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 2 FRAMES E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Columns

31

m3

38,000.00

1,178,000.00

B

Circular Columns

6

m3

38,000.00

228,000.00

C

Beams

8

m3

38,000.00

304,000.00

D

Roof beams/ concrete fascia

4

m3

38,000.00

152,000.00

E20: Formwork for in situ concrete Plain vertical sawn formwork E

Columns

539

m2

1,450.00

781,550.00

F

Circular Columns

146

m2

1,450.00

211,700.00

G

Beams

421

m2

1,450.00

610,450.00

H

Roof beams/ concrete fascia

88

m2

1,450.00

127,600.00

J

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight. 20mm Diameter

3.630

t

240,000.00

871,200.00

K

16mm Diameter

4.210

t

240,000.00

1,010,400.00

L

12mm Diameter

8.960

t

240,000.00

2,150,400.00

7.120

t

240,000.00

1,708,800.00

Mild steel bars to BS 4449, bent. M

10mm Diameter

FRAMES CARRIED TO SUMMARY

9,334,100.00

4 BEDROOM DUPLEX 4

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 3 STAIRCASES E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Staircases (flight)

4

m3

38,000.00

152,000.00

B

Landings

3

m3

38,000.00

114,000.00

C

Steps

2

m3

38,000.00

76,000.00

D

Beams

2

m3

38,000.00

76,000.00

Plain vertical sawn formwork: E

Soffits of landings

83

m2

1,450.00

120,350.00

F

Soffits of flight

44

m2

1,450.00

63,800.00

G

Sides of beams

6

m2

1,450.00

8,700.00

H

Edges of suspended slabs

14

m

400.00

5,600.00

J

Stairflights

24

m

400.00

9,600.00

K

Steps

24

m

400.00

9,600.00

Reinforcement for in situ concrete High tensile bars to BS 4449, straight and vertical. L

16mm Diameter

1.330

t

240,000.00

319,200.00

M

12mm Diameter

1.240

t

240,000.00

297,600.00

N

10mm Diameter

1.000

t

240,000.00

240,000.00

Plastered/Rendered/Roughcast coatings 12mm thick cement and sand (1:3) rendering P

Landings soffit, width exceeding 300mm

83

m

2

650.00

53,950.00

Q

Stairflight soffit, width exceeding 300mm

498

m2

650.00

323,700.00

R

Strings

144

m

225.00

32,400.00

Carried to collection

1,902,500.00

4 BEDROOM DUPLEX 5

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Sand cement/Concrete/Granolithic screeds/flooring 25mm thick cement and sand (1:4) screeded floor A

Landing floors

36

m2

830.00

29,880.00

B

Treads, 300mm wide

258

m

250.00

64,500.00

310

m

180.00

55,800.00

12mm thick cement and sand (1:3) rendering C

Risers; plain, 150mm high Stone/ConcreteQuarry/Ceramic tilling/Mosaic Granite floor tilling on cement and sand bed

D

Landing Floors

36

m2

8,000.00

288,000.00

E

Skirtings

276

m

650.00

179,400.00

F

Treads to steps

129

m

1,950.00

251,550.00

G

Risers to steps

300

m

975.00

292,500.00

23

m2

1,200.00

27,600.00

Stair Balustrades; 1000mm high purpose made designed balustrade in 75mm diameter stainless steel pipes complying to Architect's details embedded into concrete

468

m

4,800.00

2,246,400.00

Stainless steel handrails consisting of 75mm x 75mm top and bottom rail complete with bolts and nuts screwed to steel wall bracket

552

m

3,700.00

2,042,400.00

Painting/Clear finishing prepare and apply 3 coats of emulsion paints to floated surfaces, rate including floating to Architect's details. H

Rendered surfaces, width exceeding 300mm Stairs/Walkways/Balustrades

J

K

Carried to collection

5,478,030.00

Collection Page 05

1,902,500.00

Page 06

5,478,030.00

STAIRCASES CARRIED TO SUMMARY

7,380,530.00

4 BEDROOM DUPLEX 6

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 4 UPPER FLOORS E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Slabs thickness, 150-450mm, sloping not exceeding 150

114

m3

38,000.00

4,332,000.00

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight. B

12mm Diameter

13.60

t

240,000.00

3,264,000.00

C

10mm Diameter

9.57

t

240,000.00

2,296,800.00

121

m

250.00

30,250.00

1,112

m

2

1,450.00

1,612,400.00

E20: Formwork for in situ concrete Plain vertical sawn formwork to the following D

Edges of suspended slabs, height 150- 250mm Plain sawn formwork comprises of verical struts and runners

E

Soffit of slabs, slab thickness not exceeding 450mm, horizontal, height to soffit not exceeding 4.50m

UPPER FLOORS CARRIED TO SUMMARY

11,535,450.00

4 BEDROOM DUPLEX 7

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 5 ROOF G20: Carpentary/Timber framing/First fixing Sawn treated hardwood in pitched roof members A

Tie beams 150 x 50mm

1,162

m

380.00

441,560.00

B

Struts 150 x 50mm

5,128

m

380.00

1,948,640.00

C

Rafters 150 x 50mm

1,648

m

380.00

626,240.00

D

Purlins 75 x 50mm

3,821

m

260.00

993,460.00

2,322

m2

3,500.00

8,127,000.00

H72: Aluminium sheet coverings/flashings 0.55mm coloured approved stone coated aluminium coverings laid to slope not exceeding 50 degrees from the horizontal with one and half corrugation side lap and 200m end lap and fixed in accordance to manufacturers instruction (measured nett) to timber purlins at approved general spacing E

Pitched covering

F

Ridge cappings, girth 600mm

528

m

2,100.00

1,108,800.00

G

Hip capping, girth 600mm

487

m

2,100.00

1,022,700.00

ROOF CARRIED TO SUMMARY

4 BEDROOM DUPLEX 8

14,268,400.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 6 INTERNAL AND EXTERNAL WALLS F10: Brick/Block walling Hollow Sandcrete blockwork in stretcher bond bedded in cement and sand mortar mix (1:6) flush pointed. A

Walls, 230mm thick vertical

B

Dwarf walls

4,891

m2

3,200.00

15,651,200.00

187

m

2

3,200.00

598,400.00

INTERNAL AND EXTERNAL WALLS CARRIED TO SUMMARY

4 BEDROOM DUPLEX 9

16,249,600.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 7 DOORS AND WINDOWS E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Lintels

12

m3

38,000.00

456,000.00

372

m2

1,450.00

539,400.00

1.238

t

240,000.00

297,120.00

0.965

t

240,000.00

231,600.00

E20: Formwork for in situ concrete Plain vertical sawn formwork B

Lintels E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight.

C

12mm Diameter Mild steel bars to BS 4449, bent.

D

10mm Diameter DOORS L21: Metal doors/shutters/hatches purpose made decorative steel HPI security doors with steel frame in autobase paint built into blockwork and concrete surround, bedded and pointed in cement and sand mortar with mastic sealant complete with all necessary ironmongery

E

Door, size 1200 x 2100mm high

10

nr

96,500.00

965,000.00

F

Door, size 900 x 2100mm high

10

nr

78,500.00

785,000.00

L20: Timber doors/shutters/hatches 50mm thick polished hardwood timber panel door including 225mm wide treated wrought finished hardwood door frame complete with architraves and ironmongery, all complying to Architect's details G

Door, size 900 x 2100mm high

48

nr

30,000.00

1,440,000.00

H

Door, size 750 x 2100mm high

48

nr

30,000.00

1,440,000.00

Carried to collection

6,154,120.00

4 BEDROOM DUPLEX 10

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

WINDOWS L11: Metal windows/rooflights/sceens/louvres White powder coated aluminium casement windows in 5mm thick tinted glass complete with fly screen and burglar bars fit to detail A

Windows size, 1200 x 1500mm high

50

nr

58,050.00

2,902,500.00

B

Windows size, 900 x 900mm high

24

nr

48,375.00

1,161,000.00

B

Windows size, 600 x 600mm high

25

nr

32,375.00

809,375.00

Carried to collection

4,872,875.00

Collection

Page 10

6,154,120.00

Page 11

4,872,875.00

DOORS AND WINDOWS CARRIED TO SUMMARY

11,026,995.00

4 BEDROOM DUPLEX 11

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr.8 FIXTURES AND FITTINGS N10: General fixtures/furnishings/equipment Wardrobes Composite wardrobe units, in veneer-finished laminated particle board or other approved materials, comprising compartments fitted with shelves and door leaves with and including all necessary iron mongery; all to Architect's details A

B

Wardrobe size 2100mm length x 3000mm high x 600mm deep; self closing

5

nr

220,000.00

1,100,000.00

Wardrobe size 1800mm length x 3000mm high x 600mm deep; self closing

15

nr

175,000.00

2,625,000.00

1

nr

450,000.00

450,000.00

1

nr

120,000.00

120,000.00

Kitchen carbinet unit C

7600mm long x 600mm deep x 750mm high; L-shaped kitchen carbinet in accordance to Architect's details Store shelve unit

D

2270mm long x 450mm deep x 1750mm high; U-shaped and 3-tiers shelve unit in accordance to Architect's details Railings to Balcony and walls

E

Allow provisional sum of N500,000.00 for railings to balconys and walls in accordance to Architect's details

FIXTURES AND FITTINGS CARRIED TO SUMMARY

4 BEDROOM DUPLEX 12

sum

500,000.00

4,795,000.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 9 WALL FINISHES M20: Plastered/Rendered/Roughcast coatings 12mm thick cement and sand (1:3) floated smooth synthetic rendering to general surfaces complying to Architect's details. A

Walls; externally

1,538

m2

650.00

999,700.00

B

Walls; internally

5,210

m2

650.00

3,386,500.00

C

Reveals, width not exceeding 300mm

1,458

m

210.00

306,180.00

12mm thick cement and sand (1:4) floated backing to general surfaces to receive further finishes D

Walls; externally

112

m2

650.00

72,800.00

E

Walls; internally

86

m2

650.00

55,900.00

F

Reveals, width not exceeding 300mm

48

m

200.00

9,600.00

G

Plaster impression

111

m

450.00

49,950.00

1,368

m2

2,300.00

3,146,400.00

296

m

690.00

204,240.00

28

m

2

2,850.00

79,800.00

M40: Stone/ConcreteQuarry/Ceramic tilling/Mosaic High quality glazed ceramic wall tilling on cement and sand backing H

Walls; internally

J

Reveals, width not exceeding 300mm Patterned crack tiles on cement and sand backing

K

Walls; externally

Carried to collection

8,311,070.00

4 BEDROOM DUPLEX 13

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

M60: Painting/Clear finishing Vinyl mat emulsion paint as manufactured by Portland or CAPL in 3 coats to floated surfaces, rate including POP floating to Architect's details. A

Rendered surfaces, externally

1538

m

2

1,200.00

1,845,600.00

B

Rendered surfaces, internally

5210

m2

1,200.00

6,252,000.00

C

Plaster impression

111

m

350.00

38,850.00

D

Reveals, width not exceeding 300mm

316

m

400.00

126,400.00

Carried to collection

8,262,850.00

Collection

Page 13

8,311,070.00

Page 14

8,262,850.00

WALL FINISHES CARRIED TO SUMMARY

16,573,920.00

4 BEDROOM DUPLEX 14

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 10 CEILING FINISHES G20: Carpentary/Timber framing/First fixing Sawn treated hardwood in ceiling members A

Noggins 50 x 50mm

1,256

m

240.00

301,440.00

3,600.00

11,016,000.00

K40: Suspended ceilings Plaster of Paris ceiling finishes with centre rosette hunged to 50x50mm timber noggins (measured separately) including cornics fixed in accordance to the manufacturer's instructions. B

Ceiling lining

3,060

CEILING FINISHES CARRIED TO SUMMARY

4 BEDROOM DUPLEX 15

2

m

11,317,440.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr.11 FLOOR FINISHES M10: Sand cement/Concrete/Granolithic screeds/flooring 42mm thick cement and sand (1:4) floated bed to general surfaces to receive further finishes A

0

Floors, level and to falls only not exceeding 15 from 2,040

m2

830.00

1,693,200.00

horinzontal

690

m2

6,500.00

4,485,000.00

Skirtings; height 100mm including backing

768

m

650.00

499,200.00

984

m2

3,800.00

3,739,200.00

1,518

m

380.00

576,840.00

horinzontal

61

m2

3,200.00

195,200.00

Skirtings; height 100mm including backing

111

m

320.00

35,520.00

horinzontal M40: Stone/ConcreteQuarry/Ceramic tilling/Mosaic Patterned Granite floor finish on cement and sand bed B

C

0

Floors; level and to falls only not exceeding 15 from

Glazed vitrified ceramic floor tilling on cement and sand bed D

Floors; level and to falls only not exceeding 150 from horinzontal

E

Skirtings; height 100mm including backing Unglazed ceramic tilling on cement and sand bed in toilet areas

F

G

Floors; level and to falls only not exceeding 150 from

FLOOR FINISHES CARRIED TO SUMMARY

4 BEDROOM DUPLEX 16

11,224,160.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 12 ELECTRICAL SERVICES V20: LV Distribution Equipment; Metal clad Main Distrbution Board surface/ flush type as manufacured by FEDERAL ELECTRIC or MEM or BILLS including all MCB, back outlet connections to flush adaptable boxes, earth bonding, labels and fixing in accordance with manufacturer's instructions MV PANEL A

100A TPN MCCB main distribution panel (MV panel) comprising 2no 60A MCCB, 1no spare and circuit breaker

5

nr

250,000.00

1,250,000.00

B

100A change over switch

5

nr

35,000.00

175,000.00

C

100A main fuse switch

5

nr

27,000.00

135,000.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories D

4 x 150mm2 PVC/SWA/PVC copper cable

121

m

9,500.00

1,149,500.00

E

4 x 100mm2 PVC/SWA/PVC copper cable

132

m

6,000.00

792,000.00

5

nr

35,000.00

175,000.00

5

nr

20,000.00

100,000.00

DISTRIBUTION BOARDS TP&N MCB Distribution Board complete with 100A integral incoming isolator and comprising 6nr 10A stablock; 8nr 20A stablock; 12nr 30A stablock, 1nr 45A stablock and 3nr spares ways F

100A 12-Way Equipment; Metal clad isolating pattern switches or ELCB as manufactured by FEDERAL ELECTRICAL, MEM or BILLS including all necessary fuse links with quick make and quick breaks contacts and fixing in accordance with manufacturer's instructions

G

100A TP&N ELCB

Carried to collection

3,776,500.00

4 BEDROOM DUPLEX 17

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Y60: Conduit and cable trunking Conduit; straight PVC pipe with flange joints in chases/floor screeds with and inlcuding conduit boxes, locknuts, brushes, couplers, bends, reducers, cutting and other necessary accessories, rates including making good surfaces disturbed. A

25mm Diameter

2,873

m

75.00

215,475.00

1,840

m

180.00

331,200.00

986

m

180.00

177,480.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories B

4 x 6mm2 single core PVC copper cable

C

1 x 10mm2 single core PVC copper cable LUMINAIRES AND LAMPS V21: General lighting Lamp and luminaires; lighting fittings as manufactured by ABB or ASTRA or THORN or approved equal fixed to soffit including all necessary for complete installation

D

250w prismatic wall mounted halogen flood light fitting

72

nr

5,200.00

374,400.00

E

1 x 40w; 1200mm flourescent fittings

24

nr

3,800.00

91,200.00

F

60w wall bracket luminaires

360

nr

2,100.00

756,000.00

G

1 x 60w screw neck lighting fittings

72

nr

2,500.00

180,000.00

H

1 x 60w downlight luminaire fittings

72

nr

2,500.00

180,000.00

J

60w ceiling mounted bowl head lighting fitting

168

nr

2,800.00

470,400.00

K

40w, 40 bulbs ceiling hunged chandelier fittings

12

nr

120,000.00

1,440,000.00

L

"NEWCLIME" ceiling fan complete with regulator

36

nr

6,000.00

216,000.00

Carried to collection

4,432,155.00

4 BEDROOM DUPLEX 18

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Y74: Accessories for Electrical services Accessories as manufactured by MK or ABB or MEM including steel knock-out boxes fixed to form complete A

5A 1 gang 1 way switch

216

nr

600.00

129,600.00

B

5A 1 gang 2 way switch

84

nr

600.00

50,400.00

C

5A 2 gang 2 way switch

132

nr

900.00

118,800.00

D

5A 3 gang 2 way switch

24

nr

900.00

21,600.00

E

Bedside switch

20

nr

500.00

10,000.00

F

Dimmer switch

12

nr

800.00

9,600.00

G

240v fire alarm bell

5

nr

7,500.00

37,500.00

H

Break glass

5

nr

5,000.00

25,000.00

V22: General LV Power Ancillaries; low voltage power socket outlets switches and contactors as manufactured by MK or ABB or MEM or approved equal complete with accessories J

13A single switched socket outlets

192

nr

600.00

115,200.00

K

13A Twin switched socket outlets

192

nr

850.00

163,200.00

L

15A Single switched socket outlets Air conditioning

48

nr

1,500.00

72,000.00

M

20A water heater switch

25

nr

1,500.00

37,500.00

N

45A cooker control unit with light/ 13A socket outlets

5

nr

9,500.00

47,500.00

P

Telephone outlet

30

nr

750.00

22,500.00

Q

Television outlet

30

nr

750.00

22,500.00

R

Satellite outlet

30

nr

750.00

22,500.00

Carried to collection

905,400.00

4 BEDROOM DUPLEX 19

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Y60: Conduit and cable trunking Conduit; straight PVC pipe with flange joints in chases/floor screeds with and inlcuding conduit boxes, locknuts, brushes, couplers, bends, reducers, cutting and other necessary accessories, rates including making good surfaces disturbed. A

20mm Diameter

20,190

m

70.00

1,413,300.00

2

2,088

m

200.00

417,600.00

2

12,528

m

240.00

3,006,720.00

2,022

m

270.00

545,940.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories B

3 x 1.5mm single core PVC copper cable - Lighting

C

3 x 2.5mm single core PVC copper cable - Sockets

D

3 x 4mm2 PVC cable copper - Air conditioning

E

3 x 6mm2 single core PVC copper cable - Cooker sockets

522

m

375.00

195,750.00

F

1.0mm2 single core PVC copper cable TV outlets

468

m

120.00

56,160.00

G

1.0mm2 single core PVC copper cable Telephone outlets

468

m

90.00

42,120.00

H

1.0mm2 single core PVC copper cable Satellite outlets

468

m

85.00

39,780.00

5

nr

65,000.00

325,000.00

5

nr

45,000.00

225,000.00

Installation generally; supply, install, connect up and commission the complete earthing of the whole installation as at the main disribution panel, switch boards, distribution boards, generator room, transformer substation, etc. J

Earthing and bonding; 25 x 3 copper tape and 600 x 600mm mat forming a basket and bonded to foundation reinforcement complete with salt and charcoal applied as specified W52: Lightning protection

K

lightning protector/arrestor complete applied as specified

Carried to collection

6,267,370.00

4 BEDROOM DUPLEX 20

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Collection

Page 17

3,776,500.00

Page 18

4,432,155.00

Page 19

905,400.00

Page 20

6,267,370.00

ELECTRICAL SERVICES CARRIED TO SUMMARY

4 BEDROOM DUPLEX 21

15,381,425.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

ELEMENT Nr. 13 PLUMBING AND MECHANICAL SERVICES All materials supplied and installed shall be done in accordance with technical specification for mechanical installation as contained in the contract document. P30: Trenches/Pipeways/Pits for buried Engineering services A

Excavating trenches for services 500mm nominal size; 500mm average depth from 150mm below existing ground level; backfilling with selected excavated materials; disposal of surplus excavated materials

1,284

m

150.00

192,600.00

Y10: Pipelines Straight galvanised iron pipe to BS 425 in chases/trenches/floor screeds B

25mm Diameter - Cold water supply

534

m

400.00

213,600.00

C

19mm Diameter - cold water supply

1,332

m

320.00

426,240.00

D

13mm Diameter - Hot and Cold water supply

1,254

m

320.00

401,280.00

E

Non return valve

24

nr

3,000.00

72,000.00

F

Gate Valve

30

nr

3,000.00

90,000.00

G

Water meter

6

nr

12,500.00

75,000.00

Extra over galvanized iron pipes; fittings, not exceeding 65mm diameter 25mm Diameter fittings H

Elbows

300

nr

230.00

69,000.00

J

Equal tees

168

nr

280.00

47,040.00

K

Reducing tees

66

nr

280.00

18,480.00

L

Union connector

114

nr

250.00

28,500.00

M

Nipple

120

nr

120.00

14,400.00

Carried to collection

1,648,140.00

4 BEDROOM DUPLEX 22

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

19mm Diameter fittings A

Elbows

86

nr

200.00

17,200.00

B

Equal tees

48

nr

250.00

12,000.00

C

Reducing tees

14

nr

250.00

3,500.00

D

Union connector

78

nr

230.00

17,940.00

E

Nipple

51

nr

120.00

6,120.00

13mm Diameter fittings F

Elbows

89

nr

200.00

17,800.00

G

Equal tees

82

nr

250.00

20,500.00

H

Reducing tees

41

nr

250.00

10,250.00

J

Union connector

27

nr

230.00

6,210.00

K

Nipple

55

nr

120.00

6,600.00

Double trap coloured syphonic water closet with horizontal outlet with close couple 9 litres cistern and plastic cover complete with fittings

25

nr

25,500.00

637,500.00

wash hand basin 620 x 500mm with 3 taphole oval pedestal, starlite 12mm mixer with pop up waste accessories complete with wash-top to Architect's details

25

nr

14,500.00

362,500.00

Purposed made quality Jacuzzi set complete with all necessary accessories

5

nr

350,000.00

1,750,000.00

Pressed steel bath tub size; 1700 x 700mm with telephone shower

5

nr

27,000.00

135,000.00

R

Double drainer double bowl kitchen sink

5

nr

19,000.00

95,000.00

S

750mm x 750mm shower tray complete with all neccesary Accessories

20

nr

8,500.00

170,000.00

Y25: General pipeline equipment Equipment; supply, install and connect up pipeline equipment as manufactured by Eago or other approved equal with all necessary accessories for complete installation L

M

N

P

Carried to collection

3,268,120.00

4 BEDROOM DUPLEX 23

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Y25: General pipeline equipment A

Vitreous china toilet roll holder fixed to wall

30

nr

3,000.00

90,000.00

B

Stainless steel towel holder fixed to wall

30

nr

3,000.00

90,000.00

C

Mirror; 4mm silvered float glass size 600 x 450mm high

30

nr

7,000.00

210,000.00

D

50 litres ARISTON electric water heater

30

nr

27,000.00

810,000.00

E

Soap dish

30

nr

2,000.00

60,000.00

F

Soap Dispenser

30

nr

6,500.00

195,000.00

G

Hand dryer

30

nr

13,000.00

390,000.00

Straight UPVC pipes in chases/trenches/floor screeds H

100mm Diameter

465

m

520.00

241,800.00

J

75mm Diameter

360

m

450.00

162,000.00

K

50mm Diameter

210

m

450.00

94,500.00

Extra over PVC pipes; fittings, exceeding 65mm diameter 100mm Diameter L

UPVC elbow

44

nr

350.00

15,400.00

M

PVC tee

36

nr

400.00

14,400.00

N

WC connection sleeve

12

nr

1,450.00

17,400.00

P

Y radius bend

15

nr

625.00

9,375.00

Q

Pam connector

35

nr

560.00

19,600.00

R

Cleaning eye

44

nr

450.00

19,800.00

75mm Diameter S

UPVC elbow

80

nr

320.00

25,600.00

T

PVC tee

65

nr

370.00

24,050.00

U

Pam connector

55

nr

500.00

27,500.00

V

Cleaning eye

41

nr

400.00

16,400.00

Carried to collection

2,532,825.00

4 BEDROOM DUPLEX 24

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

50mm Diameter A

UPVC elbow

53

nr

280.00

14,840.00

B

PVC tee

34

nr

320.00

10,880.00

C

Cleaning eye

35

nr

400.00

14,000.00

14

nr

1,250.00

17,500.00

36

nr

25,000.00

900,000.00

Y11: Pipework ancillaries D

Traps; 50mm diameter UPVC floor drains grouted to floor bed Manholes/ Inspection Chamber

E

Manhole size 500 x 500 x 600mm deep internally constructed of 150mm thick concrete(1:3:6) base, 150mm thick sandcrete blockwork filled solid with lean concrete, 75mm thick concrete(1:3:6) benching and forming 150mm diameter half round channel, covered with cast iron, internal faces rendered in water proof cement sand mortar(1:3) including excavation, backfilling and disposal of surplus excavated materials U60: Air conditioning Units

F

Allow a provisional sum of N800,000.00 for pipe work and ancillaries in connection to Air Conditioning to be expended in accordance to Engineer's instructions

sum

800,000.00

Fire Fighting System Equipment; supply, install, connect up and commission fire fighting system as manufactured by ANGUS or other approved equal complete with piping/trunking as specified including all necessary accessories G

Fire extinguisher; ABC 9Kg capacity general purpose dry powder type

6

nr

16,500.00

99,000.00

H

240v fire alarm bell

6

nr

7,500.00

45,000.00

J

Break glass

6

nr

5,500.00

33,000.00

K

fire alarm outdoor siren

6

nr

10,550.00

63,300.00

Carried to collection

1,997,520.00

4 BEDROOM DUPLEX 25

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

Collection

Page 22

1,648,140.00

Page 23

3,268,120.00

Page 24

2,532,825.00

Page 25

1,997,520.00

PLUMBING AND MECHANICAL SERVICES CARRIED TO SUMMARY

4 BEDROOM DUPLEX 26

9,446,605.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SPORT CENTER

SUMMARY 1

SUBSTRUCTURE

13,243,320.00

2

FRAMES

9,334,100.00

3

STAIRCASES

7,380,530.00

4

UPPER FLOORS

11,535,450.00

5

ROOF

14,268,400.00

6

INTERNAL AND EXTERNAL WALLS

16,249,600.00

7

DOORS AND WINDOWS

11,026,995.00

8

FITTINGS AND FIXTURES

9

WALL FINISHES

16,573,920.00

10

CEILING FINISHES

11,317,440.00

11

FLOOR FINISHES

11,224,160.00

12

ELECTRICAL SERVICES

15,381,425.00

13

PLUMBING AND MECHANICAL SERVICES

4,795,000.00

9,446,605.00

FOUR BEDROOM SEMI-DETACHED DUPLEX (5Nos) Total carried to General Summary

4 BEDROOM DUPLEX 27

151,776,945.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

GENERAL SUMMARY

PRELIMINARIES

114,877,755.25

POLICE/FIRE SERVICE POST

1

NR

7,490,575.00

7,490,575.00

SHOPPING CENTER

1

NR

1,190,064,530.00

1,190,064,530.00

SPORT CENTER (All- Provisional) Subject to Measurement

EXTERNAL WORKS Parking and Fencing and external Drainage system (All- Provisional) Subject to Measurement

SUM

450,000,000.00

SUM

650,000,000.00

2,412,432,860.25

CONTINGENCIES

50,000,000.00 2,462,432,860.25

ADD VAT 5%

123,121,643.01

TOTAL COST OF CONSTRUCTION

2,585,554,503.26

28

GENERAL SUMMARY

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO BILL NO. 1

GENERAL CONDITIONS AND PRELIMINARIES CONDITIONS OF CONTRACT The Contractor is deemed to have carefully examined the Conditions of Contract of the Tender Documents and included against all the obligations and liabilities. The Conditions of Contract are the Standard Form of Building Contract in Nigeria for use with Quantities/ Federal Ministry of Works & Housing "LUMP SUM CONTRACT"; severally amended to suit local conditions and the peculiarities of the Works. Allow for complying with the requirements of the following clauses:CLAUSE Nr. 1. Contractor's Obligations 2. Consultants' Instructions. 3. Contract Documents.

4. Statutory Obligations, Notices, Fees and Charges. The Contractor should allow here or in his rates for any fees and charges legally demandable under this clause. 5. Levels and Setting out of the Works. 6. Materials, goods and workmanship to conform to description, testing and inspection. 7. Royalties and patent rights. 8. Foreman-in-charge. 9. Access for Architect/Supervising Officer to the works. 10. Clerk of works 11. Variations, Provisional and Prime Costs Sums. 12. Contract Bills. 13. Contract Sum. 14. Unfixed goods and materials 15. Practical completion and defects liability.

To Collection

PRELIMINARIES 29

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Conditions of Contract (contd.) Clause No. 16. Sectional completion. 17. Assignment or Sub-letting.

18. Injury to persons send property and Employer's indemnity. 19. Insurance against injury to persons and property Provide a provisional sum of N………………… for Insurances under 19(2) (a) whereby the Employer and the Contractor are Jointly indemnified up to the sum of N………………………………………… 20. Insurance of the Works against Fire etc. 21. Possession, completion and postpoment. 22. Damages for non-completion 23. Extension of time. 24. Loss and expenses caused by disturbances of regular progress of the Works 25. Determination by the Employer. 26. Determination by the Contractor. 27. Nominated Sub-contractor. 28. Nominated Suppliers 29. Artists and Tradesmen. 30. Certificates and Payments. 31. Fluctuations. 32. Outbreaks of Hostilities. 33. War Damage. 34. Antiquities. 35. Arbitration. To Collection

PRELIMINARIES 30

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Names of Parties The Employer is

INVESTRITE AND ABUJA MUNICIPAL AREA COUNCIL

The Architectr is: SHUAFEM CONSTRUCTION ASSOCIATES LIMITED

The Structural Engineer is: PRODEM LIMITED

The Quantity Surveyor is: JESIM LIMITED

The Electrical & Mechanical Engineers are: PRODEM LIMITED

To Collection

PRELIMINARIES 31

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries.

A

B

C

Site Location This work is to be carried out at a site located at …………………………… The Contractor is deemed to have inspected the site and taken notice of the site conditions as no claim arising from lack of knowledge of same will be entertainedd by the employer. Site Visit and Scope of Works. The contractor is advised to visit and inspect the site and make himself thoroughly and completely informed as to the condition of the site in its present state, the nature of the ground and full extent and character of the Works to be executed, means of access and storage space, the conditions affecting the supply of labour and the availability and supply of water. No claim for extra payment above the Contract Sum will be paid to the Contractor for want of knowledge of any conditions affecting the execution of the Works. A brief outline of the scope of the works appears immediately inside the front cover of this document and the Contractor is to allow here any sum in respect of the scope of nature of the Works. Bills of Quantities.

D

The pricing, Moneying out and totalling in these Bills of Quantities is to be in INK throughout and is to be in Nigerian Currency. The bills of quantities shall not be used for ordering materials. Any discripances found between the quantities or descriptions in the Bills and those to be ordered are reported to the Quantity Surveyor immediately.

E

The Contractor will be deemed to have included in his tender for the obligations and requirements of all items in these Contract Documents whether or not he has placed a rate or price against the items. Drawings.

F

All drawings, tracings, photo prints, etc., are the sole property of the Architect/S.O and must be returned to him upon completion of the works.

G

The Contractor shall check the whole of the dimensions on site and if any discripancy is found between the drawings and conditions on site, he shall notify the Architect/S.O immediately and request instructions.

To Collection

PRELIMINARIES 32

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries.

A

Drawings (Contd.) The Contractor shall provide and do everything necessary for the proper execution of the works according to the true intent and meaning of the drawings, whether the same may or may not be particularly shown on the drawings, provided that same is reasonably to be inferred therefrom. Figured dimensions are to be followed in preference to scaled dimensions.

B

Allow for mounting one complete set of drawings on plywood or other suitable rigid panels and keeping them on site throughout the Contract period.

C

The Contractor shall give adequate advance notice to the Architect/S.O of requirements with regards to instructions, etc. and in the absence of advance written notification to the contrary it will be assumed that the progress of the Works is not affected by the want of such notification.

D

E

Insurance Declaration On signing the contract, the Contractor shall obtain from his insurers and lodge with the Architect/S.O. a declaration that the insurance provided is strictly in accordance with clauses of the conditions of contract. Setting Out The Contractor shall accurately set out the works and include for providing all pegs, templates, instruments and labour necessary for so doing and as required by the Architect/S.O for checking this Works.

F

Excavation shall not be commenced until the permission of the Architect/S.O. is obtained.

G

Allow for providing when required on the site a "Dumpy" or Precise type level, complete with tripod and staff and allow for the free use of the leveling equipment by the Architect/S.O, Engineer or Quantity Surveyor.

H

J

J

Site Accommodation Allow for providing a suitable weather proof office on the site for the use of the Foreman-in-charge and other site staff and include for providing necessary furniture and lighting and clear away on completion. Allow for providing a suitable weather proof office on the site for the use of the Clerk of Works and consultants and large enough for the holding of site meetings and include for providing necessary furniture and lighting and clear away on completion. Allow for providing a temporary hut for the Watchman complete with lighting and necessary furniture and clear away on completion. To Collection

PRELIMINARIES 33

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Site Accommodation (contd.) A

Allow for providing and maintaining all necessary temporary Buildings for storage and protection of goods and materials on site and other work that may be brought or executed on the site including the tools and materials of sub-contractors and remove on completion. Sheds for the storage of cement are to have floors raised from ground. Electricity

B

Allow for providing all temporary lighting and power for the works including that for use by special tradesmen and sub-contractors; paying all fees and charges and providing all necessary temporary mains and clearing away and making good on completion. Water

C

Allow for providing all water required for the works including that for sub-contractors. The water is to be clean, fresh water.

D

Allow for executing all temporary plumbing and paying all fees and charges incurred in the connection and supply of the water for building purposes and the removal of all temporary plumbing on completion. Temporary Works

E

The Contractor shall ensure that all temporary electrical, water and other installations are executed in accordance with the requirements of the Authorities concerned. Temporary Fencing and Access Roads.

F

Allow for all necessary temporary access roads, crossroads, crossovers, gangways, gates, entrances and the like required, maintain and clear away and make good on completion.

G

Allow for adequate temporary security fencing to the perimeter of site, maintain and clear away and make good on completion. Welfare and Safety.

H

Allow for providing adequate latrine accommodation and keeping same in a clean and sanitary condition to the satisfaction of the Health Authorities and clearing away latrines and soil whenever necessary and making good all works disturbed.

To Collection

PRELIMINARIES 34

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Welfare and Safety (Contd.) A

Allow for providing sheds and workshops for the use of the workmen on the site and maintaining and subsequently dismantling and carting away on completion and allow for providing and maintaining welfare and safety measures and amenities of a suitable standard approved by the Architect/S.O. or required by the authorities.

B

The Contractor is to provide on site a First Aid Box or Cupboard prominently marked with the words "First Aid" for the purpose of treating any of his employees injured on site. The contents of this box or cupboard are to comply in all respects with the Factories Ordinance. The Contractor is to ensure that there is always adequate stocks in the First Aid Box or Cupboard which is to be produced and opened for the inspection of the Architect/ S.O. on request. Watching and Lighting

C

Allow for providing all necessary guards, day and night watchmen and lighting for the protection of the works and the safety of the public. Hoardings and Barreirs

D

Allow for providing all fans, gantries, hoardings guard rails, barriers, or any other form of special protection to all sides of the buildings and site as necessary to protect adjoining property, persons, vehicles and the like from injury. Ordering of Materials

E

Upon receipt of the order to commence the works, the contracttor shall immediately place orders for all the required materials and will be held responsible for any delays occurring due to the late placing of such orders.

F

The contractor shall, if so requested by the Architect/S.O. make available to him all documents in connection with the ordering of materials for the works, showing agreed delivery dates, sources of supply and the like.

G

If upon receiving quotations for any materials required for the works it appears that delivery by the dates quoted will delay the works, the contractor shall inform the Architect/S.O. of this fact before placing the orders.

To Collection

PRELIMINARIES 35

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Time and Progress A

The works shall be proceeded with in such sections and sequences as will affect completion of all works within the time for completion or as directed by the Architect/S.O.

B

Immediately upon signing the Contract, or before signing the Contract, if requested, the Contractor shall in collaboration with Sub-Contractors submit to the Architect/S.O. for acceptance programmed and progress charts to cover all activities on the site and shall record progress thereon throughout the execution of the works.

C

The Contractor shall arrange for representatives to attend site meetings as and when reasonably required by the Architect/ S.O. and shall provide seating and other necessary facilities for such meetings.

D

The Contractor's attention is drawn to his responsibility for the co - ordination and programming of sub-contractor's work. The Contractor is expected to arrange suitable programmes with his sub-contractors and to check regularly that such programmes are adhered to. Where delays arise in connection with sub - con tract works, the Contractor will be expected to have been aware of such at an early stage and to have taken appropriate action defined in the sub - contract document by the giving of such notices as may be required in preparation for determination of same. Determination shall not be affected without the prior consent of the Architect/S.O. but requests for extensions of the Contract period on the grounds of delay by sub - contractor will not be considered unless the contractor can establish requirements. Materials found on the site

E

Any sand, laterite, gravel, or other building materials discovered on the site shall be property of the Employer and shall not be used in the construction of the Works without the prior written consent of the Architect/S.O. The market price of the materials so used shall be allowed to the Employer by the Contractor and the Contract Sum adjusted accordingly. Precious articles or antiquities found on the site shall be the property of the Employer and shall be handed over to the Architect/S.O

To Collection

PRELIMINARIES 36

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Scaffolding and Plant A

Allow for providing all scaffolding, hoists, tackle and other plant, profiles, templates, centerings and equipment generally required for the proper, safe and efficient execution of the works and providing all labour and things required by the Architect/S.O. for testing and measuring the Works and for weighting, measuring or testing the efficiency of any portion of the works.

B

The Contractor is particularly to note that scaffolding, staging and the like is to be provided both for the execution of his own work and that of sub - contractors employed under this Contract, including that required solely for the execution of work by sub - contractors.

C

Allow for providing all gangways, walkways, planking, deckings, temporary platforms, etc. necessary to construct and afford access to or between all parts of the works. Records

D

Allow for keeping such books, accounts and other documents and records as are necessary to show the increases in costs incurred or the reductions obtained under Clause 31 of the Conditions of Contract and furnishing such books, accounts documents and records to the Quantity Surveyor or other person authorised to receive them at monthly intervals or as requested throughout the duration of the Contract.

E

In the event of adjustments arising under Clause 31 of the Conditions of Contract, the Contractor shall submit monthly fully priced out and totalled, statements showing the total adjustments claimed, together with separate sheets relating individually to the various sub-contractors. Protection of the works

F

Allow for covering up and protecting from injury from weather or from any cause, all new work, also for supplying all temporary doors, protection to windows and any other requisite protection for the whole of the works executed whether by the Contractor or special tradesmen or sub-contractors and any damage caused must be made good by the Contractor at his own expense.

G

During inclement weather the Contractor shall suspend such parts of the Works for such time as the Architect/S.O. may decide and shall protect from injury all works then in the course of erection.

To Collection

PRELIMINARIES 37

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Tests and Samples A

Allow for carrying out tests of any materials, either before or after use in the works and for providing samples of all materials and specimens of colours for approval as required by the Architect/S.O. or Engineer before or application in the Works. Covering Up

B

No work shall be covered up until it has been examined and approved by the Architect/S.O.

C

In the case of work executed against provisional quantities in the Bills of Quantities (and therefore subject to measurement) the Contractor shall notify the Quantity Surveyor before proceeding to cover up the Works. Opening Up.

D

The Contractor shall, at the request of the Architect/S.O. open up for inspection any work covered; and should the Contractor refuse or fail to comply with such request, the Architect/S.O. may employ other workmen to open up same. If the said work has been covered in contravention of the Architect/S.O.'s Instructions and if on being opened up it be found not in accordance with the drawings or instructions of the Architect/ S.O. , the expenses of opening up and covering up again, whether done by the Contractor or other workmen, shall be borne by, or recoverable from the Contractor or may be deducted as aforesaid. If the work has not been covered up in contravention of such instructions and be found in accordance with the said drawings, etc. , then the expenses aforesaid shall be borne by the Employer and be added to the Contract Sum. Existing Installations

E

Allow for protecting and maintaining all pipes, ducts and cables met in excavations, for keeping all ditches, gullies and channels clear and unobstructed and for making good any damaged caused to public or private roads, paths, kerbs and drains and paying all costs and charges incurred. Temporary Storm Water Drainage.

F

Allow for ensuring that the whole of the site is kept free from the risk of stormwater flooding and providing such temporary ditches, gullies and the like as may be necessary and for subsequently backfilling such excavations and making good. Any damage arising from non-compliance with this clause is to be made good at the Contractor's own expense.

To Collection

PRELIMINARIES 38

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Prevention of Nuisance A

Allow for taking all necessary precautions with regard to the order and method of execution of the work to avoid causing disturbance or nuisance to the users and occupiers of existing buildings and premises adjacent to the Works and for complying with any directions of the Architect/S.O. in this respect. Access for Workmen

B

The Contractor shall at all times give access to workmen employed by the Employer or by local or other authorities or any other parties and use of proper, sufficient, and if required, special scaffolding, hoists and ladders and provide them with water and lighting, etc. Delays

C

The Contractor will be deemed to have made allowance for all delays caused by difficulty in obtaining labour and materials or suspension of part or the whole of the Works due to adverse weather conditions. Overtime and Completion

D

The whole of the Works are to be completed by the time stated in the Contract and no extra will be allowed in respect of overtime paid to achieve this.

E

In the event of the Works falling behind programme for reasons other than those which would entitle the Contractor to an extension of time under the Conditions of Contract, then the Contractor shall, if so instructed by the Architect/S.O. arrange, at no extra cost, double-shift working on the site until such time as progress on the site is in accordance with the programme.

F

If overtime is specifically ordered in writing by the Architect/S.O. in respect of extra works, the net extra costs, over and above normal daily rates, will be paid to the Contractor. Dismissal by Request

G

The Contractor shall, on written request of the Architect/S.O. or his representative on the site, immediately dismiss from the Works any person employed by him thereon who may, in the opinion of the Architect/S.O be incompetent or misconduct himself and such person shall not again be employed on the Works without the written permission of the Architect/S.O.

To Collection

PRELIMINARIES 39

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Imported Materials A

Where materials are to be supplied from outside Nigeria, the cost of such materials C.I.F., Apapa Docks together with landing charges, duty and other Government taxes will be set against the P.C or Provisional Sum included in the Bills of Quantities. The Contractor will be required to collect and clear the materials from Apapa Docks, handle, load and transport them to the site and will be responsible for any loss or damage to the materials after they are landed; an item for this is included in the Bills of Quantities after the relevant P.C Sums. Prime Cost Sums

B

The following items in connection with prime cost sums are in addition to the Contractor's obligations described elsewhere (for example, provision of scaffolding, etc.)

C

Receipted vouchers for all articles for which prime cost amounts are included in the Bills of Quantities must be produced at the final settlement of accounts and the final certificate will not be issued until such receipts have been produced.

D

The Contractor shall allow for checking Nominated Suppliers' invoices and quotations, etc., before placing orders in respect of P.C Items and shall be solely responsible for ensuring that all materials so ordered are sufficient and correct in quantity and contain due allowance for waste, etc.

E

The Contractor shall allow for checking all materials supplied by the Nominated Suppliers at the time of receipt on site, unpacking, re-packing and taking all necessary action in respect of insurance claims and the re-ordering of broken or damaged articles.

F

Where the Contractor is required to 'Fix Only' materials supplied by Nominated Suppliers or others, the rates inserted in the Bills of Quantities are to allow for taking delivery, stacking, storing and protecting until required, assembling as necessary and getting into position before fixing.

To Collection

PRELIMINARIES 40

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Prime Cost Sums (cont'd) A

Where the term 'attendance' or 'attend upon' is used in the Bills of Quantities in connection with Nominated Sub-Contractor's work, or work executed by others, the Contractor shall allow for the use of standing scaffolding, canteens, sanitary accommodation, office accommodation, space for storage of plant and materials and for providing light and water and clearing away rubbish and for taking delivery of all materials when received on the site, unloading, handling, stacking or storing until required and hoisting into position. The Contractor shall allow for affording maximum co-operation in arranging that builder's work is carried out, as far as possible to suit the convenience of the Sub-contractors. The Contractor shall obtain from the sub-contractors their requireements for recesses, chases, holes and the like so that these may be formed correctly as the work proceeds. No extra charge will be allowed for cutting chases, holes, etc., out of proper sequence. Provisional Sums

B

Work executed against provisional sums shall be measured and valued in accordance with clause 11 of the Conditions of Contract with the exception that the cost of materials falling within the scope of P.C items elsewhere in the Bills of Quantities will be offset against those P.C items. Omission of P.C or Provisional Sums

C

The Employer reserves the right to omit any P.C or Provisional Sum from the Contract and no claim for loss of profit arising from such omissions will be entertained. Direct Payment by Employer for Items covered by P.C or Provisional Sums.

D

The Employer reserves the right to supply and pay direct for any items covered in this Contract by P.C or Provisional Sums.

E

No adjustment will be made to the Contractor's profit and attendance on P.C Sums (whether expressed as a lump sum or as a percentage) should this right be exercised.

To Collection

PRELIMINARIES 41

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries. Advertisements A

The Contractor shall not display, or permit the display of any advertisement within the boundaries of the site or upon any temporary fencing, hoardings, plant, etc., save upon the written instructions of the Architect/S.O. Site Board

B

Provide and erect a site board showing the title of the Contract, names and addresses of the Consultants, Nominated Suppliers and Sub-Contractors and such other information as may be required by the Architect/S.O who shall approve the design layout and colours of the board. Lettering shall be 'cut-out' plywood or plastic of an approved thickness, and shall be 100mm high for the main title, and 50mm or 38mm high elsewhere. The whole board shall be maintained in good condition, repainted as necessary, and removed when no longer required. Clearing of Rubbish

C

Allow for clearing away all shavings, cuttings and other rubbish as it accumulates from time to time during the progress of the Works and on completion, including that of sub-contractors and special tradesmen and the disposal of all materials condemned by the Architect/S.O. Clearing on Completion

D

Allow for cleaning down the whole of the premises including cleaning glass both sides and cleaning off all floors, pavings, metalwork, finishings and fittings throughout, touching up generally and removing all stains, dirt and surplus materials and rubbish and leaving the Works and site in a clean and tidy condition and ready for immediate use, with all damage to property, roads, paths and drains, etc., made good to the satisfaction of the Architect/S.O. Defects after Completion

E

Allow for inspecting the Works at the end of the Defects Liability Period and making good all defects in accordance with clause 15 of the Conditions of Contract. Allow also for inspecting and making good such defects as may be of an urgent nature during the Defects Liability Period.

To Collection

PRELIMINARIES 42

N

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DESCRIPTION

NO Preliminaries.

A

B

C

Exterminate and Prevent Pests Allow for effectively destroying all vermin, insects and pests to the whole area of the site and taking all preventive measures to maintain the site in a clean and sanitary condition to the satisfaction of the Architect/S.O. (See also item in "work below ground floor slab" of each building for special treatment of ground under buildings) Advance Payment/Performance Bond Allow for providing an Advance Payment/Performance Bond obtainable from an approved Bank or Insurance Company. Project Vehicle Allow for provion of an approved 2Nrs Hilux car as consultants' project Vehicle including fueling and maitaining, driver salaries etc. throughout the duration of the project, and shall be handed over to client on completion of the project.

21,000,000.00

To Collection Below COLLECTION Page Prel/1 Page Prel/2 Page Prel/3 Page Prel/4 Page Prel/5 Page Prel/6 Page Prel/7 Page Prel/8 Page Prel/9 Page Prel/10 Page Prel/11 Page Prel/12 Page Prel/13 Page Prel/14 Page Prel/15 Preliminaries Carried to Grand Summary

PRELIMINARIES 43

114,877,755.25

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

POLICE POST/FIRE OFFICE SUBSTRUCTURE (ALL PROVISIONAL) Excavations and Earthwork A

B

C

Excavate topsoil to remove vegetable top soil maximum depth not exceeding 150mm and cart away to a distance of 2.00m from site

119

m

2

50.00

5,950.00

from stripped level not exceeding 1.50m deep.

50

m

3

575.00

28,750.00

Ditto pit to receive column bases

22

m

3

575.00

12,650.00

11

m

3

220.00

2,420.00

28

m

3

180.00

5,040.00

101

m2

1,350.00

136,350.00

56

m2

40.00

2,240.00

151

m2

55.00

8,305.00

Excavate trench for foundation starting

Filling D

Remove surplus excavated material and cart away from site

E

Return fill and ram excavated material around pits and Foundation.

F

Approved imported laterite hardcore filling well rammed and consilidated in layers in 150mm layers.

Surface Treatment G

Level and compact bottom of excavation to receive concrete.

H

Prepare and apply "Dieldrex" 20 anti-terminate treatment to sides and bottom of excavation.

201,705.00

To Collections

POLICE/FIRE SERVICE POST44

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

substructure cont'd concrete Work Insitu Concrete mix 1:10 aggregate in A

50mm thick blinding

73

m2

2,100.00

35,700.00

17

m

3

42,000.00

42,000.00

42,000.00

210,000.00

plain insitu concrete Grade 20 developing crushing strenght of 21N/mm2 in 28 days in: B

Foundation trenches Reinforced in-situ concrete (grade 25) developing strenght of 21N/mm2 at 28 days in:

C

Column Base

1

m

3

D

Column

1

m

3

E

Ground Beam

1

m3

F

150mm bed

2

m3

5 Reinforcement Round hot rolled tensile deformed bar reinforcement to BS4449 and 4461 including all necessary cuttings, bends, hooks, tying, wires etc. Column Bases G

12mm diameter bar

86

Kg

300.00

25,800.00

Column H

16mm diameter bar

110

Kg

300.00

33,000.00

J

10mm diameter bar

76

Kg

300.00

22,800.00

Ground Beam K

16mm diameter bar

120

Kg

300.00

36,000.00

L

10mm diameter bar

98

Kg

300.00

29,400.00

119

m2

1,150.00

136,850.00

Slab Single layer BRC mesh reinforcement to BS 4483 reference A193 weighing 3,02Kg/m2 laid in bed with 150mm side and end laps (measured nett) in: M

Floor Slab

To Collections 571,550.00

POLICE/FIRE SERVICE POST45

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

Substructure cont'd Formwork Sawn formwork to A.

Sides of Columns base

2

m2

B

Sides of column

3

m2

1,650.00

8,250.00

5 C

Sides floor bed 150mm high

15

m

400.00

6,000.00

10

m

2

4,800.00

48,000.00

Blockwork sandcrete hollow blocks with cavities filled solid with plain in situ concrete (1:4:8) - 100mm aggregate D

230mm walls

To Collections

62,250.00

COLLECTIONS PAGE 1

201,705.00

PAGE 2

571,550.00

PAGE 3

62,250.00

SUBSTRUCTURE CARRIED TO SUMMARY

835,505.00

POLICE/FIRE SERVICE POST46

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

CONCRETE WORK Reinforced in-situ concrete (grade 25) developing strenght of 2/mm2 at 28 days in: A

Column

1

m

3

42,000.00

42,000.00

B

Roof Beam

1

m

3

42,000.00

42,000.00

Reinforcement Round hot rolled tensile deformed bar reinforcement to BS 4449 and 4461 including all necessary cuttings, bends hooks, tying wires etc. in Column C

16mm Diameter

180

Kg

300.00

54,000.00

D

10mm Diameter

90

Kg

300.00

27,000.00

Roof Beam E

16mm Diameter

165

Kg

300.00

49,500.00

F

10mm Diameter

87

Kg

300.00

26,100.00

Sawn Formwork G

Sides of Column

3

m2

1,650.00

4,950.00

H

Sides and Soffit of roof beam

19

m

360.00

6,840.00

252,390.00 CONCRETE WORK CARRIED TO SUMMARY

POLICE/FIRE SERVICE POST47

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

BLOCKWORK

Sandcrete hollow block in blocks sizes 450 x 230mm high built in cement mortar (1:4) A

230mm thick wall

380

BLOCKWORK CARRIED TO SUMMARY

m2

3,800.00

1,444,000.00

1,444,000.00

POLICE/FIRE SERVICE POST48

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ROOFING Aluminium roofing sheets 0.55mm gauge longspan aluminium roofing sheets fixed to timber purlin with hooks and bolts in accordance with the manufactures instruction A

Roofing

212

m

2

4,850.00

1,028,200.00

B

Ridge capping 700mm girth

12

m

2,450.00

29,400.00

C

Gutter valley 700mm girth

34

m

2,450.00

83,300.00

D

450mm flashing twice bent one end dressed over and other end turned in groove in blockwork

22

m

1,650.00

36,300.00

ROOFING CARRIED TO SUMMARY

1,177,200.00

POLICE/FIRE SERVICE POST49

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

CARPENTARY AND JOINERY

Treated Sawn Hardwood A

150 x 50mm Rafters at 1200mm centres

211

m

380.00

80,180.00

B

150 x 50mm Tie beams at 1200mm centres

186

m

380.00

70,680.00

C

150 x 50mm King post at 1200mm centres

24

m

380.00

9,120.00

D

100 x 50mm struts

18

m

320.00

5,760.00

E

50 x 75mm purlins at 900mm centres

21

m

260.00

5,460.00

F

50 x 50mm Noggins at 600mm centres

176

m

240.00

42,240.00

CARPENTARY & JOINERY CARRIED TO SUMMARY

213,440.00

POLICE/FIRE SERVICE POST50

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

DOORS AND WINDOWS

A

HARDWOOD TIMBER 44mm Thick solid core veneer plywood polished flush doors complete with metal frame and high quality lock set (measured separately), Doors 900 x 2100mm high

4

No

30,000.00

120,000.00

B

Door 750 x 2100mm high

2

No

30,000.00

60,000.00

6

No

4,500.00

27,000.00

6

No

6,500.00

39,000.00

6

No

600.00

3,600.00

Supply and fix approved ironmongery to doors C

75 toilet privacy bolts

D

Cylinder lockset or other equal and approved type with lever handle furniture

E

Plastic door stopper screwed to floor

WINDOWS ALUMINIUM SLIDING WINDOWS F

Composite window overall size 900x 1200mm high comprising sliding window size 900 x 1200 Fixed to block work and concrete

6

No

20,000.00

120,000.00

G

Ditto 600 x 600mm ditto

2

No

12,500.00

25,000.00

BURGLAR PROOFING TO WINDOWS Fabricate and install complete Mild Steel bars consisting of 16mm high tensile vertical and horizontal bars welded together including priming in red oxide paint and one finishing coat gloss paint. H

1200 x 900mm high.

6

No

9,500.00

57,000.00

J

600 x 600mm high

2

No

7,500.00

15,000.00

DOORS AND WINDOWS CARRIED TO SUMMARY

466,600.00

POLICE/FIRE SERVICE POST51

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

PLUMBING AND ENGINEERING INSTALLATIONS SANITARY APPLIANCES Supply anf fix the following sanitary fittings in accordance with the manufacturer's instructions TWYFORD Vitreous china low level water Closet white suite with "P" trap or equal approved type by "CCA" complete with all necessary accessories

2

Nr

28,000.00

56,000.00

TWYFORD 560 x 405mm Wash Hand basin complete with pedestal and all accessories

2

Nr

18,000.00

36,000.00

750 x 750mm shower tray complete with all necessary accessories approved by 'CCA'

2

Nr

20,000.00

40,000.00

Towel rail Chrome plated steel rail and holder; Screwed to wall with and including drive screws

2

Nr

3,500.00

7,000.00

Toilet roll holder; stainless stell with a wooden thief proof holder fixed to wall

2

Nr

1,400.00

2,800.00

Mirrow; 4mm silvered floated glass; 600 x 450mm with arised edges

2

Nr

5,500.00

11,000.00

2

Nr

1,500.00

3,000.00

148

m

350.00

51,800.00

J

Straight galvanised iron pipe in chases/trenches/ Floor screed 38mm Diameter

18

m

1,200.00

21,600.00

K

25mm Diameter

21

m

900.00

18,900.00

L

19mm Diameter

14

m

410.00

5,740.00

M

13mm Diameter

8

m

240.00

1,920.00

N

Extra over 38mm UPVC Pipe; for Fittings Elbows;38

5

Nr

180.00

900.00

P

Equal tee;38x38x38

16

Nr

180.00

2,880.00

Q

Reducing Tee;38x38x25

12

Nr

180.00

2,160.00

R

Union Connector;38

8

Nr

180.00

1,440.00

S

12

Nr

180.00

2,160.00

T

Sockets;25 Extra over 25mm UPVC Pipe; for Fittings Elbows;25

8

Nr

180.00

1,440.00

U

Reducing Tee;25x25x19

8

Nr

180.00

1,440.00

A

B

C

D

E

F

G

Floor drain; stainless steel; mounted flush with floor finish and 50mm low level S-trap COLD WATER SUPPLY Trenches/Pipesways/Pits for buried Engineering Services

H

Excavating trenches for services 500mm norminal size: 500mm average depth from 150mm below excavated materials; disposal of surplus excavated materials

Pipelines

To Collections

268,180.00

POLICE/FIRE SERVICE POST52

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

A

Union Connector;25

8

Nr

180.00

1,440.00

B

Sockets;25

6

Nr

180.00

1,080.00

Extra over 19mm UPVC Pipe; for Fittings C

Elbows;19

6

Nr

80.00

480.00

D

Equal tee;19x19x19

8

Nr

80.00

640.00

E

Reducing Tee;19x19x13

1

Nr

80.00

80.00

F

Union Connector;19

4

Nr

80.00

320.00

G

Sockets;19

6

Nr

80.00

480.00

Extra over 13mm UPVC Pipe; for Fittings H

Elbows;13

8

Nr

80.00

640.00

J

Equal tee;13x13x13

4

Nr

80.00

320.00

K

Nipples; 13

2

Nr

80.00

160.00

L

Union Connector;13

8

Nr

80.00

640.00

M

Sockets;13

5

Nr

80.00

400.00

Gate valve; 19mm; bronze body; with 2 nr connections to galvanised mild steel pipe

3

Nr

2,000.00

6,000.00

Stop cork; 13mm; bronze body; with 2 nr connections to galvanised mild steel pipe

8

Nr

800.00

6,400.00

Pipework Ancillaries N

P

WASTE WATER INSTALLATION Pipe work The following in approved PVC waste water discharge pipe with and including all accessories to match Q

100mm Diameter

97

m

700.00

67,900.00

R

32mm Diameter

13

m

550.00

7,150.00

Extra over PVC Discharge pipe S

100 x 100mm WC connector

1

Nr

800.00

800.00

T

32 x 32mm elbow

4

Nr

800.00

3,200.00

U

Tee 50 x 50mm

3

Nr

800.00

2,400.00

Inspection Chamber 450 x 450 x 450mm high inspection chamber with blockwall on reinforced 100mm thick concrete base and including precast 75mm thidk reinforced concrete cover.

2

Nr

30,000.00

60,000.00

V

To Collections

160,530.00

POLICE/FIRE SERVICE POST53

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

TESTING AND COMMISSIONING A

B

Test the entire installation in accordance with the Enginner's specification

100,000.00

Preparing Drawings;information required in the Engineer's specification;3Nr copies;1Nr negative and 2Nr prints; binding into two sets;for the Employer.

50,000.00

To collections

150,000.00

COLLECTIONS PAGE 9

268,180.00

PAGE 10

160,530.00

PAGE 11

150,000.00

PLUMBING AND ENGINEERING INSTALLATIONS CARRIED TO SUMMARY

POLICE/FIRE SERVICE POST54

578,710.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELECTRICAL ENGINEERING INSTALLATIONS Accessories fo Electrical Services ACCESSORIES; LIGHTING SWITCHES; AS SPECIFIED RATE TO INCLUDE GALVANISED STEEL KNOCKOUT BOX SET IN MORTICES IN WALL; (FLUSH MOUNTED)

A

1 gang 1 way "MEM' or equal approved

4

Nr

2,500.00

10,000.00

B

1 gang 2 way Ditto

4

Nr

2,500.00

10,000.00

C

2 gang 2 way Ditto

2

Nr

2,500.00

5,000.00

D

3 gang 2 way Ditto

2

Nr

2,500.00

5,000.00

CONDUIT AND CABLE TRUNKING CABLE AND CONDUIT IN FINAL CIRCUIT;RADIAL MAIN CIRCUIT; PVC INSULATED AND COLOUR CODED CABLE TO BS 6004 TABLE 1A; DRAWN INTO AND INCLUDING 20MM DIAMETER HEAVY GUAGE PVC CONDUIT; RATE TO INCLUDE FOR ALL CABLE ANCILLARIES DEEMED NECCESARY FOR A COMPLETE INSTALLATION E

3Nr single Core 2.5mm2 Cables

110

m

1,250.00

137,500.00

F

3Nr single Core 4mm2 Cables

46

m

1,800.00

82,800.00

ACCESSORIES; SOCKETS; AS SPECIFIED RATE TO INCLUDE GALVANISED STEEL KNOCKOUT BOX SET IN MORTICES IN WALL; (FLUSH MOUNTED)

G

13A 1 gang Double Pole "MEM' or equal approved

3

Nr

2,500.00

7,500.00

H

13A 2 gang Double Pole "MEM' or equal approved

1

Nr

2,500.00

2,500.00

J

20A 3 pin 1 gang Double Pole "MEM' or equal approved

1

Nr

3,200.00

3,200.00

K

15A 3 pin 1 gang Double Pole "MEM' or equal approved

1

Nr

2,800.00

2,800.00

1 x 18W Flourscent, Ceiling Mounted with Diffuser

1

Nr

1,800.00

1,800.00

Surface mounted Twin Flourscent with Opal Diffuser with 1 x 36 TLD Flourescent

1

Nr

3,500.00

3,500.00

Surface mounted Single Flourscent with Opal Diffuser with 1 x 18 TLD Flourescent

1

Nr

3,500.00

3,500.00

Recessed Vertical Downlighter witrh High Frequency Electronic ballast

1

Nr

2,400.00

2,400.00

Ceiling Mounted Fitting in Die cast Aluminium Satin Glass With Aluminium reflector

1

Nr

2,900.00

2,900.00

R

Compact Flourescent wall Mirrow Light

1

Nr

1,200.00

1,200.00

S

Newclime celing fan complete with regulators

1

Nr

9,500.00

9,500.00

Fittings and Accessories L M

N

P Q

ELECTRICAL ENGINEERING INSTALLATIONS: Carried to Summary

291,100.00

POLICE/FIRE SERVICE POST55

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT NO. 8 FLOOR, WALL AND CEILING FINISHINGS FLOOR FINISHES INTERNAL WORKS 300 x 300 x 8mm Vitrified ceramic floor tiles laid on cement and sand screeded bed (measured separately)

134

m

2

3,800.00

509,200.00

B

Ditto 19x150mm skirting

19

m

1,500.00

28,500.00

C

Ditto treads 300mm wide

6

m

1,850.00

11,100.00

134

m

2

630.00

84,420.00

A.

Cement and sand (1:3) beds and backings D

42mm Screeded bed to receive vitrified ceramic floor tiles

E

Ditto screeded bed to receive treads

6

m

465.00

2,790.00

F

12mm floated backing

19

m

465.00

8,835.00

G

EXTERNAL WORKS 300 x 300 x 8mm Vitrified ceramic floor tiles laid on cement and sand screeded bed (measured separately)

4

m2

3,800.00

15,200.00

H

Ditto 19x150mm skirting

6

m

1,500.00

9,000.00

J

Ditto treads 300mm wide

4

m

1,850.00

7,400.00

K

Cement and sand (1:3) bed 42mm Screeded bed to receive vitrified ceramic floor tiles

4

m2

630.00

2,520.00

L

Ditto screeded bed to receive treads

4

m

465.00

1,860.00

M

12mm floated backing

6

m

465.00

2,790.00

WALL FINISHES Internal works 12mm cement and sand (1:4) smooth rendering to N

Walls

134

m

2

450.00

60,300.00

P

Surfaces not exceeding 100 -200mm wide

10

m

90.00

900.00

Q

Ditto not exceeding 300mm wide

3

m

135.00

405.00

R

GLAZED WALL TILES 200 x 200x6mm Colour glazed wall tiles fixed with approved adhesive on cement and sand floated backing (measured separately)

12

m2

3,500.00

42,000.00

S

Ditto reveals100-200mm wide

5

m

1,500.00

7,500.00

T

Ditto 19x150mm Apron

4

m

1,500.00

6,000.00

U

Ditto risers 150mm high Cement and sand (1:3) beds and backings

2

m

1,500.00

3,000.00

12mm floated backing to receive glazed ceramic wall tiles (measured separately)

12

m2

450.00

5,400.00

W

Ditto reveals100-200mm wide

5

m

90.00

450.00

X

Ditto 19x150mm Apron

4

m

90.00

360.00

Y

Ditto risers 150mm high

2

m

90.00

180.00

V

To collection

810,110.00

POLICE/FIRE SERVICE POST56

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT NO. 8 continued External works 12mm cement and sand (1:4) smooth rendering to: A

Walls

C

224

m2

450.00

100,800.00

Sides not exceeding 200mm width

6

m

90.00

540.00

D

Ditto not exceeding 300mm wide

3

m

135.00

405.00

E

Isolated circular columns 150 radius GLAZED WALL TILES

5

m

135.00

675.00

200 x 200x6mm Colour glazed wall tiles fixed with approved adhesive on cement and sand floated backing (measured separately) on risers 150mm high Cement and sand (1:3) beds and backings

10

m

1,500.00

15,000.00

12mm floated backing to receive glazed ceramic tiles riser 150mm high (m/s)

10

m

90.00

900.00

134

m2

4,800.00

643,200.00

27

m2

4,800.00

129,600.00

F

G

Ceiling Finishes Internal works ALUMINIUM SUSPENDED CEILING SYSTEM H

600 x 600mm Aluminium suspended ceiling in concealed grids; suspended ceiling tiles or other equal and approved External works

J

600 x 600mm Aluminium suspended ceiling in concealed grids; suspended ceiling tiles or other equal and approved 12mm cement and sand (1:4) smooth rendering on:

K

Protect all works in this section

Item To Collection

891,120.00

COLLECTIONS PAGE 13

810,110.00

PAGE 14

891,120.00

FLOOR, WALL AND CEILING FINISHINGS: Carried to Summary

1,701,230.00

POLICE/FIRE SERVICE POST57

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT NO 10 PAINTING AND DECORATING INTERNAL WORK Prepare and aply two undercoats and one finishings coat of emulsion paint on: A

Walls

134

m

2

1,200.00

160,800.00

224

m

2

1,650.00

369,600.00

External works Prepare and aply chemical décor glossy textured paint from approved manufacturer on: B

Rendered walls

PAINTING AND DECORATING Carried to Summary

530,400.00

POLICE/FIRE SERVICE POST58

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

SUMMARY A

SUBSTRUCTURE

835,505.00

B

FRAME

252,390.00

C

INTERNAL AND EXTERNAL WALLS

1,444,000.00

D

ROOF AND ROOF COVERINGS

1,177,200.00

E

CARPENTARY AND JOINERY

213,440.00

F

DOORS, WINDOWS AND IRONMONGERY

466,600.00

G

PLUMBING AND ENGINEERING INSTALLATIONS

578,710.00

H

ELECTRICAL INSTALLATIONS

291,100.00

J

FLOOR, WALLS AND CEILING FINISHINGS

K

PAINTING AND DECORATING

1,701,230.00

530,400.00

7,490,575.00

POLICE/FIRE POST

POLICE/FIRE SERVICE POST59

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SHOPPING MALL ELEMENT Nr. 1 BLOCK A SUBSTRUCTURE (ALL PROVISIONAL) D20: Excavation and Filling. 22,500

m

2

40.00

900,000.00

4,575

m3

575.00

2,630,625.00

4,050

m3

575.00

2,328,750.00

5,111

m3

220.00

1,124,420.00

3,514

m3

180.00

632,520.00

86

m3

1,350.00

116,100.00

hardcore materials obtained off site

1,410

m

3

2,100.00

2,961,000.00

H

Level and compact bottom of excavation

1,321

m2

40.00

52,840.00

J

Dieldrex or other equal and approved antitermite treatment 1,321

m

2

55.00

72,655.00

57

m2

2,100.00

119,700.00

701

m

3

42,000.00

29,442,000.00

A

Excavate topsoil average depth not exceeding 150mm

B

Excavating trenches, width exceeding 0.3m maximum depth not exceeding 1.50m

C

Excavating pits (900nr), maximum depth not exceeding 2.00m

D

Dispose excavated materials off site, in spoil heap away from site

E

Filling to excavations, thickness exceeding 250mm, materials arising from excavations

F

150mm laterite filling in layers

G

Filling to make up levels, thickness not exceeding 150mm,

solution spread to faces of excavations E10: In situ concrete Plain in situ concrete (1:10)-40mm aggregate K

Blinding beds, thickness not exceeding 50mm Plain in situ concrete (1:3:6)-20mm aggregate

L

Foundations Reinforced in situ concrete (1:2:4)-19mm aggregate

M

Beds/ attached steps (150mm thick)

1,360

m

3

42,000.00

57,120,000.00

N

Column bases

1311

m3

42,000.00

55,062,000.00

P

Column (900nos)

211

m

3

42,000.00

8,862,000.00

Carried to collection

161,424,610.00

SHOPPING MALL 60

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

E20: Formwork for in situ concrete Plain vertical sawn formwork 544

m

2

1,650.00

897,600.00

1,242

m

2

1,650.00

2,049,300.00

C

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight 20mm Diameter

121.110

t

300,000.00

36,333,000.00

D

16mm Diameter

14.812

t

300,000.00

4,443,600.00

E

12mm Diameter

6.411

t

300,000.00

1,923,300.00

8.123

t

300,000.00

2,436,900.00

9,831

m2

1,150.00

11,305,650.00

7,112

m2

4,800.00

34,137,600.00

A

Edges of beds, height not exceeding 250mm

B

Sides of column

Mild steel bars to BS 4449, bent. F

10mm Diameter Fabric mesh A192 weighting 42kg/m2 laid as detailed in manufacturer's manual

G

Ground floor bed/Attached ramp F10: Brick/Block walling Sandcrete blockwork in stretcher bond bedded in cement and sand mortar mix (1:6) flush pointed, filled solid with lean concrete

H

Walls, 230mm thick vertical

EXTERNAL RENDERING J

15mm thick cement and sand (1:4) smooth rendering to face of the wall

912

m

2

650.00

592,800.00

912

m2

1,650.00

1,504,800.00

PAINTING AND DECORATION K

Prepare prime and apply one undercoat and two finishing coats of high quality "DULUX" emulsion paint on rendered wall (rate including floating)

Carried to collection

95,624,550.00

SHOPPING MALL 61

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

Collection

Page 01

161,424,610.00

Page 02

95,624,550.00

SUBSTRUCTURE CARRIED TO SUMMARY

257,049,160.00

SHOPPING MALL 62

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 2 FRAMES E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Columns

312

m

3

42,000.00

13,104,000.00

C

Beams

61

m

3

42,000.00

2,562,000.00

D

Roof beams/ concrete fascia

26

m3

42,000.00

1,092,000.00

5,921

m2

1,650.00

9,769,650.00

E20: Formwork for in situ concrete Plain vertical sawn formwork E

Columns

G

Beams

562

m2

1,650.00

927,300.00

H

Roof beams/ concrete fascia

343

m2

1,650.00

565,950.00

J

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight. 20mm Diameter

18.110

t

300,000.00

5,433,000.00

K

16mm Diameter

29.710

t

300,000.00

8,913,000.00

L

12mm Diameter

19.910

t

300,000.00

5,973,000.00

29.180

t

300,000.00

8,754,000.00

Mild steel bars to BS 4449, bent. M

10mm Diameter

FRAMES CARRIED TO SUMMARY

57,093,900.00

SHOPPING MALL 63

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 3 STAIRCASES E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Staircases (flight)

18

m

3

42,000.00

756,000.00

B

Landings

12

m

3

42,000.00

504,000.00

C

Steps

8

m3

42,000.00

336,000.00

D

Beams

11

m

3

42,000.00

462,000.00

Plain vertical sawn formwork: E

Soffits of landings

104

m2

1,650.00

171,600.00

F

Soffits of flight

132

m2

1,650.00

217,800.00

G

Sides of beams

24

m2

1,650.00

39,600.00

H

Edges of suspended slabs

64

m

400.00

25,600.00

J

Stairflights

128

m

400.00

51,200.00

K

Steps

321

m

400.00

128,400.00

Reinforcement for in situ concrete High tensile bars to BS 4449, straight and vertical. L

16mm Diameter

1.480

t

300,000.00

444,000.00

M

12mm Diameter

5.012

t

300,000.00

1,503,600.00

N

10mm Diameter

0.913

t

300,000.00

273,900.00

Plastered/Rendered/Roughcast coatings 12mm thick cement and sand (1:3) rendering P

Landings soffit, width exceeding 300mm

344

m

2

650.00

223,600.00

Q

Stairflight soffit, width exceeding 300mm

498

m

2

650.00

323,700.00

R

Strings

211

m

225.00

47,475.00

Carried to collection

5,508,475.00

SHOPPING MALL 64

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

Sand cement/Concrete/Granolithic screeds/flooring 25mm thick cement and sand (1:4) screeded floor A

Landing floors

112

m2

830.00

92,960.00

B

Treads, 300mm wide

347

m

250.00

86,750.00

481

m

180.00

86,580.00

12mm thick cement and sand (1:3) rendering C

Risers; plain, 150mm high Stone/ConcreteQuarry/Ceramic tilling/Mosaic Granite floor tilling on cement and sand bed

D

Landing Floors

112

m2

8,500.00

952,000.00

E

Skirtings

411

m

650.00

267,150.00

F

Treads to steps

308

m

1,950.00

600,600.00

G

Risers to steps

321

m

975.00

312,975.00

141

m2

1,650.00

232,650.00

Stair Balustrades; 1000mm high purpose made designed balustrade in 75mm diameter stainless steel pipes complying to Architect's details embedded into concrete

1,811

m

5,700.00

10,322,700.00

Stainless steel handrails consisting of 75mm x 75mm top and bottom rail complete with bolts and nuts screwed to steel wall bracket

2,911

m

4,800.00

13,972,800.00

Painting/Clear finishing prepare and apply 3 coats of emulsion paints to floated surfaces, rate including floating to Architect's details. H

Rendered surfaces, width exceeding 300mm Stairs/Walkways/Balustrades

J

K

Carried to collection

26,927,165.00

Collection Page 05

5,508,475.00

Page 06

26,927,165.00

STAIRCASES CARRIED TO SUMMARY

32,435,640.00

SHOPPING MALL 65

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 4 UPPER FLOORS E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Slabs thickness, 150-450mm, sloping not exceeding 15

0

1,360

m

3

42,000.00

57,120,000.00

E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight. B

12mm Diameter

191.86

t

300,000.00

57,558,000.00

C

10mm Diameter

51.40

t

300,000.00

15,420,000.00

2,176

m

350.00

761,600.00

9,067

m2

1,650.00

14,960,550.00

E20: Formwork for in situ concrete Plain vertical sawn formwork to the following D

Edges of suspended slabs, height 150- 250mm Plain sawn formwork comprises of verical struts and runners

E

Soffit of slabs, slab thickness not exceeding 450mm, horizontal, height to soffit not exceeding 4.50m

UPPER FLOORS CARRIED TO SUMMARY

145,820,150.00

SHOPPING MALL 66

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 5 ROOF G20: Carpentary/Timber framing/First fixing Sawn treated hardwood in pitched roof members A

Tie beams 150 x 50mm

4,118

m

380.00

1,564,840.00

B

Struts 150 x 50mm

9,711

m

380.00

3,690,180.00

C

Rafters 150 x 50mm

8,717

m

380.00

3,312,460.00

D

Purlins 75 x 50mm

7,231

m

260.00

1,880,060.00

4,821

m2

4,850.00

23,381,850.00

H72: Aluminium sheet coverings/flashings 0.55mm coloured approved stone coated aluminium coverings laid to slope not exceeding 50 degrees from the horizontal with one and half corrugation side lap and 200m end lap and fixed in accordance to manufacturers instruction (measured nett) to timber purlins at approved general spacing E

Pitched covering

F

Ridge cappings, girth 600mm

811

m

2,450.00

1,986,950.00

G

Hip capping, girth 600mm

521

m

2,450.00

1,276,450.00

ROOF CARRIED TO SUMMARY

37,092,790.00

SHOPPING MALL 67

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 6 INTERNAL AND EXTERNAL WALLS F10: Brick/Block walling Hollow Sandcrete blockwork in stretcher bond bedded in cement and sand mortar mix (1:6) flush pointed. A

Walls, 230mm thick vertical

18,648

m

2

3,800.00

70,862,400.00

B

Dwarf walls

5,128

m2

3,800.00

19,486,400.00

INTERNAL AND EXTERNAL WALLS CARRIED TO SUMMARY

SHOPPING MALL 68

90,348,800.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 7 DOORS AND WINDOWS E10: In situ concrete Reinforced in situ concrete (1:2:4)-19mm aggregate A

Lintels

33

m

3

42,000.00

1,386,000.00

614

m2

1,650.00

1,013,100.00

3.310

t

300,000.00

993,000.00

4.612

t

300,000.00

1,383,600.00

E20: Formwork for in situ concrete Plain vertical sawn formwork B

Lintels E30: Reinforcement for in situ concrete High tensile bars to BS 4449, straight.

C

12mm Diameter Mild steel bars to BS 4449, bent.

D

10mm Diameter DOORS L21: Metal doors/shutters/hatches purpose made decorative steel HPI security doors with steel frame in autobase paint built into blockwork and concrete surround, bedded and pointed in cement and sand mortar with mastic sealant complete with all necessary ironmongery

E

Door, size 1800 x 2100mm high

522

nr

165,000.00

86,130,000.00

F

Door, size 900 x 2100mm high

12

nr

78,500.00

942,000.00

L20: Timber doors/shutters/hatches 50mm thick polished hardwood timber panel door including 225mm wide treated wrought finished hardwood door frame complete with architraves and ironmongery, all complying to Architect's details H

Door, size 900 x 2100mm high

20

nr

45,000.00

900,000.00

J

Door, size 750 x 2100mm high

590

nr

38,500.00

22,715,000.00

Carried to collection

115,462,700.00

SHOPPING MALL 69

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

WINDOWS L11: Metal windows/rooflights/sceens/louvres White powder coated aluminium casement windows in 5mm thick tinted glass complete with fly screen and burglar bars fit to detail A

Windows size, 1500 x 1200mm high

150

nr

88,500.00

13,275,000.00

B

Windows size, 1200 x 1200mm high

32

nr

54,000.00

1,728,000.00

C

Windows size, 600 x 900mm high

704

nr

20,250.00

14,256,000.00

Carried to collection

29,259,000.00

Collection

Page 10

115,462,700.00

Page 11

29,259,000.00

DOORS AND WINDOWS CARRIED TO SUMMARY

144,721,700.00

SHOPPING MALL 70

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

ELEMENT Nr. 8 WALL FINISHES M20: Plastered/Rendered/Roughcast coatings 12mm thick cement and sand (1:3) floated smooth synthetic rendering to general surfaces complying to Architect's details. A

Walls; externally

16,512

m2

650.00

10,732,800.00

B

Walls; internally

28,112

m2

650.00

18,272,800.00

C

Reveals, width not exceeding 300mm

5,116

m

210.00

1,074,360.00

12mm thick cement and sand (1:4) floated backing to general surfaces to receive further finishes D

Walls; externally

44

m2

650.00

28,600.00

E

Walls; internally

1,121

m2

650.00

728,650.00

F

Reveals, width not exceeding 300mm

68

m

200.00

13,600.00

G

Plaster impression

19

m

450.00

8,550.00

Carried to collection

30,859,360.00

SHOPPING MALL 71

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY M60: Painting/Clear finishing Vinyl mat emulsion paint as manufactured by Portland or CAPL in 3 coats to floated surfaces, rate including POP floating to Architect's details. A

Rendered surfaces, externally

16,512

m2

1,650.00

27,244,800.00

B

Rendered surfaces, internally

28,112

m

2

1,650.00

46,384,800.00

C

Plaster impression

19

m

350.00

6,650.00

D

Reveals, width not exceeding 300mm

316

m

400.00

126,400.00

Carried to collection

73,762,650.00

Collection

Page 13

30,859,360.00

Page 14

73,762,650.00

WALL FINISHES CARRIED TO SUMMARY

104,622,010.00

SHOPPING MALL 72

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY ELEMENT Nr. 10 CEILING FINISHES G20: Carpentary/Timber framing/First fixing Sawn treated hardwood in ceiling members A

Noggins 50 x 50mm

12,694

m

280.00

3,554,320.00

1,650.00

14,960,550.00

K40: Asbestos ceilings Asbestos ceiling finishes with centre rosette hunged to 50x50mm timber noggins (measured separately) including cornics fixed in accordance to the manufacturer's instructions. B

Ceiling lining

9,067

m2

CEILING FINISHES CARRIED TO SUMMARY

18,514,870.00

SHOPPING MALL 73

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY ELEMENT Nr.11 FLOOR FINISHES M10: Sand cement/Concrete/Granolithic screeds/flooring 42mm thick cement and sand (1:4) floated bed to general surfaces to receive further finishes A

Floors, level and to falls only not exceeding 150 from 18,134

m2

830.00

15,051,220.00

horinzontal

231

m2

8,500.00

1,963,500.00

Skirtings; height 100mm including backing

421

m

650.00

273,650.00

horinzontal

17,222

m2

3,800.00

65,443,600.00

Skirtings; height 100mm including backing

6,722

m

380.00

2,554,360.00

681

m

2

3,200.00

2,179,200.00

horinzontal M40: Stone/ConcreteQuarry/Ceramic tilling/Mosaic Patterned Granite floor finish on cement and sand bed B

C

0

Floors; level and to falls only not exceeding 15 from

Glazed vitrified ceramic floor tilling on cement and sand bed D

Floors; level and to falls only not exceeding 150 from

Unglazed ceramic tilling on cement and sand bed in toilet areas F

0

Floors; level and to falls only not exceeding 15 from horinzontal

FLOOR FINISHES CARRIED TO SUMMARY

SHOPPING MALL 74

87,465,530.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY ELEMENT Nr. 12 ELECTRICAL SERVICES V20: LV Distribution Equipment; Metal clad Main Distrbution Board surface/ flush type as manufacured by FEDERAL ELECTRIC or MEM or BILLS including all MCB, back outlet connections to flush adaptable boxes, earth bonding, labels and fixing in accordance with manufacturer's instructions MV PANEL A

100A TPN MCCB main distribution panel (MV panel) comprising 2no 60A MCCB, 1no spare and circuit breaker

B

100A change over switch

C

100A main fuse switch

8

nr

300,000.00

2,400,000.00

121

nr

35,000.00

4,235,000.00

80

nr

27,000.00

2,160,000.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories D

4 x 150mm2 PVC/SWA/PVC copper cable

6,512

m

12,500.00

81,400,000.00

E

4 x 100mm2 PVC/SWA/PVC copper cable

1,411

m

8,500.00

11,993,500.00

482

nr

40,000.00

19,280,000.00

162

nr

20,000.00

3,240,000.00

DISTRIBUTION BOARDS TP&N MCB Distribution Board complete with 100A integral incoming isolator and comprising 6nr 10A stablock; 8nr 20A stablock; 12nr 30A stablock, 1nr 45A stablock and 3nr spares ways F

100A 12-Way Equipment; Metal clad isolating pattern switches or ELCB as manufactured by FEDERAL ELECTRICAL, MEM or BILLS including all necessary fuse links with quick make and quick breaks contacts and fixing in accordance with manufacturer's instructions

G

100A TP&N ELCB

Carried to collection

124,708,500.00

SHOPPING MALL 75

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY Y60: Conduit and cable trunking Conduit; straight PVC pipe with flange joints in chases/floor screeds with and inlcuding conduit boxes, locknuts, brushes, couplers, bends, reducers, cutting and other necessary accessories, rates including making good surfaces disturbed. A

25mm Diameter

18,916

m

120.00

2,269,920.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories B

4 x 6mm2 single core PVC copper cable

14,993

m

220.00

3,298,460.00

C

1 x 10mm2 single core PVC copper cable

8,761

m

220.00

1,927,420.00

LUMINAIRES AND LAMPS V21: General lighting Lamp and luminaires; lighting fittings as manufactured by ABB or ASTRA or THORN or approved equal fixed to soffit including all necessary for complete installation D

250w prismatic wall mounted halogen flood light fitting

432

nr

8,000.00

3,456,000.00

E

1 x 40w; 1200mm flourescent fittings

211

nr

3,800.00

801,800.00

F

60w ceiling mounted bowl head lighting fitting

162

nr

2,800.00

453,600.00

G

"NEWCLIME" ceiling fan complete with regulator

512

nr

8,500.00

4,352,000.00

Carried to collection

16,559,200.00

SHOPPING MALL 76

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY Y74: Accessories for Electrical services Accessories as manufactured by MK or ABB or MEM including steel knock-out boxes fixed to form complete A

5A 1 gang 1 way switch

216

nr

1,200.00

259,200.00

B

5A 1 gang 2 way switch

84

nr

1,200.00

100,800.00

C

5A 2 gang 2 way switch

132

nr

1,200.00

158,400.00

D

5A 3 gang 2 way switch

24

nr

1,200.00

28,800.00

E

240v fire alarm bell

16

nr

7,500.00

120,000.00

F

Break glass

16

nr

5,000.00

80,000.00

V22: General LV Power Ancillaries; low voltage power socket outlets switches and contactors as manufactured by MK or ABB or MEM or approved equal complete with accessories G

13A single switched socket outlets

543

nr

1,200.00

651,600.00

H

13A Twin switched socket outlets

543

nr

1,200.00

651,600.00

Carried to collection

2,050,400.00

SHOPPING MALL 77

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

Y60: Conduit and cable trunking Conduit; straight PVC pipe with flange joints in chases/floor screeds with and inlcuding conduit boxes, locknuts, brushes, couplers, bends, reducers, cutting and other necessary accessories, rates including making good surfaces disturbed. A

20mm Diameter

26,531

m

70.00

1,857,170.00

Y61: HV/LV cable and wiring Cables; PVC insulated cable as manufactured by NOCACO or approved equal drawn into conduits or ducts or laid down into trunking or laid in trenches including cable loops, terminations, glands and all other accessories 2

B

3 x 1.5mm single core PVC copper cable - Lighting

12,479

m

650.00

8,111,350.00

C

3 x 2.5mm2 single core PVC copper cable - Sockets

14,052

m

480.00

6,744,960.00

12

nr

120,000.00

1,440,000.00

12

nr

80,000.00

960,000.00

Installation generally; supply, install, connect up and commission the complete earthing of the whole installation as at the main disribution panel, switch boards, distribution boards, generator room, transformer substation, etc. J

Earthing and bonding; 25 x 3 copper tape and 600 x 600mm mat forming a basket and bonded to foundation reinforcement complete with salt and charcoal applied as specified W52: Lightning protection

K

lightning protector/arrestor complete applied as specified

Carried to collection

19,113,480.00

SHOPPING MALL 78

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY Collection

Page 17

124,708,500.00

Page 18

16,559,200.00

Page 19

2,050,400.00

Page 20

19,113,480.00

ELECTRICAL SERVICES CARRIED TO SUMMARY

162,431,580.00

SHOPPING MALL 79

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY ELEMENT Nr. 13 PLUMBING AND MECHANICAL SERVICES All materials supplied and installed shall be done in accordance with technical specification for mechanical installation as contained in the contract document. P30: Trenches/Pipeways/Pits for buried Engineering services A

Excavating trenches for services 500mm nominal size; 500mm average depth from 150mm below existing ground level; backfilling with selected excavated materials; disposal of surplus excavated materials

6,211

m

250.00

1,552,750.00

2,461

m

320.00

787,520.00

821

m

320.00

262,720.00

Y10: Pipelines Straight galvanised iron pipe to BS 425 in chases/trenches/floor screeds B

19mm Diameter - cold water supply

C

13mm Diameter - Hot and Cold water supply

D

Non return valve

45

nr

3,000.00

135,000.00

E

Gate Valve

33

nr

3,000.00

99,000.00

F

Water meter

18

nr

12,500.00

225,000.00

Extra over galvanized iron pipes; fittings, not exceeding 65mm diameter 25mm Diameter fittings H

Elbows

310

nr

230.00

71,300.00

J

Equal tees

211

nr

280.00

59,080.00

K

Reducing tees

61

nr

280.00

17,080.00

L

Union connector

81

nr

250.00

20,250.00

M

Nipple

112

nr

120.00

13,440.00

Carried to collection

3,243,140.00

SHOPPING MALL 80

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY 19mm Diameter fittings A

Elbows

24

nr

200.00

4,800.00

B

Equal tees

13

nr

250.00

3,250.00

C

Reducing tees

21

nr

250.00

5,250.00

D

Union connector

32

nr

230.00

7,360.00

E

Nipple

21

nr

120.00

2,520.00

13mm Diameter fittings F

Elbows

44

nr

200.00

8,800.00

G

Equal tees

61

nr

250.00

15,250.00

H

Reducing tees

38

nr

250.00

9,500.00

J

Union connector

65

nr

230.00

14,950.00

K

Nipple

82

nr

120.00

9,840.00

Double trap coloured syphonic water closet with horizontal outlet with close couple 9 litres cistern and plastic cover complete with fittings

536

nr

32,000.00

17,152,000.00

wash hand basin 620 x 500mm with 3 taphole oval pedestal, starlite 12mm mixer with pop up waste accessories complete with wash-top to Architect's details

536

nr

25,500.00

13,668,000.00

Y25: General pipeline equipment Equipment; supply, install and connect up pipeline equipment as manufactured by Eago or other approved equal with all necessary accessories for complete installation L

M

Carried to collection

30,901,520.00

SHOPPING MALL 81

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY Y25: General pipeline equipment A

Vitreous china toilet roll holder fixed to wall

536

nr

3,000.00

1,608,000.00

B

Mirror; 4mm silvered float glass size 600 x 450mm high

481

nr

7,000.00

3,367,000.00

C

Hand dryer

12

nr

13,000.00

156,000.00

Straight UPVC pipes in chases/trenches/floor screeds H

100mm Diameter

4,932

m

520.00

2,564,640.00

J

75mm Diameter

2,612

m

450.00

1,175,400.00

K

50mm Diameter

4,118

m

450.00

1,853,100.00

Extra over PVC pipes; fittings, exceeding 65mm diameter 100mm Diameter L

UPVC elbow

98

nr

350.00

34,300.00

M

PVC tee

48

nr

400.00

19,200.00

N

WC connection sleeve

32

nr

1,450.00

46,400.00

P

Y radius bend

36

nr

625.00

22,500.00

Q

Pam connector

61

nr

560.00

34,160.00

R

Cleaning eye

44

nr

450.00

19,800.00

112

nr

320.00

35,840.00

75mm Diameter S

UPVC elbow

T

PVC tee

86

nr

370.00

31,820.00

U

Pam connector

55

nr

500.00

27,500.00

V

Cleaning eye

42

nr

400.00

16,800.00

Carried to collection

11,012,460.00

SHOPPING MALL 82

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY 50mm Diameter A

UPVC elbow

27

nr

280.00

7,560.00

B

PVC tee

21

nr

320.00

6,720.00

C

Cleaning eye

21

nr

400.00

8,400.00

432

nr

1,250.00

540,000.00

191

nr

30,000.00

5,730,000.00

44

nr

16,500.00

726,000.00

6

nr

7,500.00

45,000.00

Y11: Pipework ancillaries D

Traps; 50mm diameter UPVC floor drains grouted to floor bed Manholes/ Inspection Chamber

E

Manhole size 500 x 500 x 600mm deep internally constructed of 150mm thick concrete(1:3:6) base, 150mm thick sandcrete blockwork filled solid with lean concrete, 75mm thick concrete(1:3:6) benching and forming 150mm diameter half round channel, covered with cast iron, internal faces rendered in water proof cement sand mortar(1:3) including excavation, backfilling and disposal of surplus excavated materials

Fire Fighting System Equipment; supply, install, connect up and commission fire fighting system as manufactured by ANGUS or other approved equal complete with piping/trunking as specified including all necessary accessories G

Fire extinguisher; ABC 9Kg capacity general purpose dry powder type

H

240v fire alarm bell

J

Break glass

22

nr

5,500.00

121,000.00

K

fire alarm outdoor siren

12

nr

10,550.00

126,600.00

Carried to collection

7,311,280.00

SHOPPING MALL 83

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY

Collection

Page 22

3,243,140.00

Page 23

30,901,520.00

Page 24

11,012,460.00

Page 25

7,311,280.00

PLUMBING AND MECHANICAL SERVICES CARRIED TO SUMMARY

SHOPPING MALL 84

52,468,400.00

PROPOSED DEVELOPMENT OF NYANYA COMMUNITY SUMMARY 1

SUBSTRUCTURE

257,049,160.00

2

FRAMES

57,093,900.00

3

STAIRCASES

32,435,640.00

4

UPPER FLOORS

5

ROOF

37,092,790.00

6

INTERNAL AND EXTERNAL WALLS

90,348,800.00

7

DOORS AND WINDOWS

144,721,700.00

8

WALL FINISHES

104,622,010.00

9

CEILING FINISHES

145,820,150.00

18,514,870.00

10 FLOOR FINISHES

87,465,530.00

11 ELECTRICAL SERVICES

162,431,580.00

12 PLUMBING AND MECHANICAL SERVICES

52,468,400.00

SHOPPING CENTER Total carried to General Summary

1,190,064,530.00

SHOPPING MALL 85