Awes Shipbuilding Contract





PREFACE

During the 124 AWES Standing Committee Meeting, held in December 1995 in Belfast, it was decided to elaborate a new issue of the Standard Shipbuilding Contract of AWES, as proposed by the Director. The aim was to prepare a new text to substitute the last one drafted back in 1972. Since then and after a long process of consultations, exchanges and several ad-hoc meetings the new text, as presented now, has been worked out.

Vadm. Renato Sicurezza Mr. Taavi Soininvaara Mr. Wim Timmers Dr. Giuseppe Volpé to complete this specialized task while attending their daily work within a spirit of full co-operation and openness to dialogue at the two decisive meetings in Hamburg and Barcelona. Special mention deserves Dr. Mathias Münchau, as diligent and effective coordinator during the final production phase. I hope that this Standard Contract Form be useful to all shipyards of the AWES Associations, with this intention we have worked.

I firstly have to acknowledge with thanks the effort carried out by the Drafting Group made up by: Dr. Michael Baumhauer Mr. Jyrki Heinimaa Dr. Mathias Münchau Mr. José Esteban Pérez Mr. Ruud Michael Prehn Mr. Schouten Dr. Stefan Schrandt



José Esteban Pérez AWES DIRECTOR



INDEX

ARTICLE 1: par. a par. b par. c par. d par. e

SUBJECT OF CONTRACT Vessel's description and main characteristics ........................................9 Yard Number........................................................................................10 Vessel's Registration and Classification...............................................10 Decisions of the Classification Society.................................................10 Subcontracting .....................................................................................10

ARTICLE 2: par. a par. b

INSPECTION AND APPROVAL Inspection during Construction............................................................. 11 Approval...............................................................................................11

ARTICLE 3: par. a par. b par. c par. d par. e

MODIFICATIONS Purchaser's Modifications.....................................................................13 Contractor's Modifications ....................................................................13 Modifications by Regulatory Bodies and Classification Society ...........13 Payment for adjustments of price.........................................................14 Information ........................................................................................... 14

ARTICLE 4: par. a par. b par. c par. d par. e par. f

TRIALS Notice ...................................................................................................15 Weather Conditions..............................................................................15 Carrying out..........................................................................................15 Method of Acceptance or Rejection .....................................................15 Effect of Acceptance ............................................................................16 Surplus Consumable Stores................................................................. 16

ARTICLE 5:

GUARANTEE FOR SPEED, CARGO CARRYING CAPACITYAND FUEL CONSUMPTION Speed................................................................................................... 17 Deadweight capacity ............................................................................17 Grain/bale capacity...............................................................................18 Fuel Consumption ................................................................................18

par. a par. b par. c par. d ARTICLE 6: par. a par. b par. c par. d par. e



DELIVERY OF THE VESSEL Time and Place of Delivery .................................................................20 Delivery Documentation .......................................................................20 Liquidated Damages and Premiums ....................................................21 Force Majeure......................................................................................21 Permissible Delay.................................................................................21



ARTICLE 7: par. a par. b par. c par. d par. e par. f

PRICE Contract Price.......................................................................................23 Instalments...........................................................................................23 Payment procedures ............................................................................23 Payment for Modifications....................................................................23 Payment for liquidated Damages and Premiums.................................23 Prompt Payment...................................................................................24



ARTICLE 8: par. a par. b

PROPERTY General Plans, Specifications and Working Drawings .........................25 Property in the Vessel ..........................................................................25



ARTlCLE 9:

INSURANCE............... ............................... ................................ ..........26

ARTlCLE 10:

DEFAULT BY THE PURCHASER............. ................................ ..........27

ARTlCLE 11:

DEFAULT BY THE CONTRACTOR ............................... ..................... 28

ARTlCLE 12: par. a par. b

GUARANTEE Extent of Guarantee.............................................................................29 Guarantee Engineer............................................................................. 30



ARTlCLE 13:

CONTRACT EXPENSES...................... ................................ ...............31

ARTICLE 14:

PATENTS......................................... ............................... ..................... 32

ARTICLE 15: par. a par. b par. c

INTERPRETATION, REFERENCE TOEXPERT AND ARBITRATION Interpretation........................................................................................33 Reference to expert¢s assessment...................................................... 33 Arbitration.............................................................................................33 

ARTICLE 16:

CONDITION FOR THE CONTRACT TO BECOME EFFECTIVE.........................................................................35



ARTICLE 17:

LEGAL DOMICILE...................................... ............................... ..........36

ARTICLE 18:

ASSIGNMENT ............................ ............................... .......................... 37

ARTlCLE 19:

LIMITATION OF LIABILITY............................. ............................... .....38





ARTlCLE 20: par. a par. b

ADDRESSES FOR CORRESPONDENCE........................... ................... Contractor's addresses.........................................................................39 Purchaser's addresses.........................................................................40

                                      





CONTRACT

Between: .................................................................................................................................... ................................................................................................................................................... ................................................................................................................................................... ................................................................................................................................................... a company organized and existing under the laws of ................................................................ ................................................................................................................................................... with its registered office in ......................................................................................................... hereinafter called the "PURCHASER" and ................................................................................................................................................... ................................................................................................................................................... ................................................................................................................................................... ................................................................................................................................................... a company organized and existing under the laws of ................................................................ ................................................................................................................................................... with its registered office in.......................................................................................................... hereinafter called the "CONTRACTOR",

IT IS HEREBY AGREED AND STIPULATED AS FOLLOWS:





ARTICLE 1: SUBJETCT OF CONTRACT

 (a) VESSEL's description and main characteristics

contained in the general plan(s) and not mentioned in the specification(s) and vice versa is to be understood as included in both the foregoing documents.

The CONTRACTOR undertakes to build at the CONTRACTOR's yard in ..................... ..................................... (hereinafter called the"Shipyard") and to deliver to the

The VESSEL shall have the dimensions and characteristics stated in the

PURCHASER,to accept who orders undertakes delivery and of .................................................................... .................................................................... .................................................................... .................................................................... .................................................................... of approximately......................................... .................................................................... .................................................................... metric tons deadweight, hereinafter called the "VESSEL", subject to and in accordance with this CONTRACT and relevant specification(s) No (s) .................. dated ....................... and general plan(s) No(s) ..........................................................

Specifications, main particulars: including the following  ...length

between perpendiculars, approximately: .................................... ............................................................ -....breadth moulded, approximately: .............................................................. .............................................................. ..............................................................  ...depth to ........................ deck from base line, approximately: ................... ............................................................  ...design draft in salt water, approximately: .................................... ............................................................  ...

signed by both which partiesform (together the "Specifications"), an integral part of this CONTRACT, although not attached hereto.

scantling draft: ..................................... ............................................................ ............................................................  ...deadweight at design draft (specific gravity 1.025): .................................... ............................................................ ............................................................  ...main propulsion plant: ......................... ...........................................................  ...type: .................................................... ............................................................ ...........................................................  ... maximum continuous rating: ............ ..................................................KWatt  ...trial speed of the VESSEL with a clean hull, on even keel at the design draft, with the main propulsion machinery

In the event of any conflict between this CONTRACT and the Specifications the provisions of this CONTRACT shall prevail. In the event of any conflict between the specification(s) and the general plan(s) the provisions of the specification(s) shall prevail. Notwithstanding the above, it is understood that the foregoing specification(s) and general plan(s) are complementary and that everything





developing an output of ... KWatt (measured at the outgoing shaft) under good conditions, viz. wind not exceeding 2 beaufort and in calm, deep,current free water ...................... ............................................................ ............................................................ knots ...................................................  ... other main particulars of the VESSEL ............................................................

Bodies"). Classification, survey and testing charges relating to the CONTRACTOR's obligations and items of supply under this CONTRACT shall be for the account of the CONTRACTOR. The registration of the VESSEL shall be carried out by the PURCHASER and the costs and expenses thereof shall be for PURCHASER's account.

(d) Decisions of theClassification Society

(b) Yard Number The VESSEL shall, for the purpose of identification only, be known as Yard Number ...................................................... ....................................................................

The decisions of the Classification Society shall be final and binding on both contracting parties as to the VESSEL's compliance or non-compliance with the rules and regulations, observance of which is to be controlled by the Classification Society.

(c) VESSEL's Registration and Classification The VESSEL shall comply with the laws, rules, regulations and enactments published and in force in ....................... on

(e) Subcontracting

.................................................................... .................................................................... as stated in the Specifications.

subcontract part of the work to third parties.

The CONTRACTOR has the right to

The VESSEL shall be built under the survey of .................................................... (hereinafter the "Classification Society") to .................................................................... Class and in accordance with normal shipbuilding practices in ............................ for new vessels of the type and general characteristics of the VESSEL. The VESSEL shall also comply with the rules, regulations and requirements of other relevant authorities as set out in the Specifications (hereinafter the "Regulatory 



ARTICLE 2: INSPECTION AND APPROVAL 

(a) Inspection during Construction

During construction of the VESSEL, the CONTRACTOR shall give the PURCHASER's Representative reasonable advance notice of important tests and inspections in order to enable him to attend. Failure of the Representative to be present at such tests

The PURCHASER shall have the right to have the VESSEL and all engines, machinery, outfit and equipment intended therefore inspected during construction by one or more (up to a maximum of ...) authorized representative(s) (jointly the "Representative") to whom the CONTRACTOR shall grant free access for such purposes during working hours to the VESSEL and to the Shipyard and workshops, save and except areas which are controlled for purposes of national security. The CONTRACTOR will obtain for the PURCHASER's right of access to subcontractor¢s premises as far as possible. The inspection will be at the PURCHASER's risk and expense.

and inspections shall be deemed to be a after waiverdue of notice this right to be present. Should the PURCHASER elect to use as the Representative to firms or persons other than or in addition to its full time employees, different or in addition to the ones established in the provisions of this CON-TRACT, admittance of such firms or persons and their duties shall be subject to the CONTRACTOR's prior written approval, which shall not be unreasonably withheld.

The CONTRACTOR will make available for the PURCHASER's Representative appropriate office space at the Shipyard

(b) Approval

furnished telephone, fax and other basic officewith facilities at CONTRACTOR's costs and expenses. All telecommunication charges shall be for account of the PURCHASER.

The CONTRACTOR shall send to the PURCHASER (or its Representative) for approval three copies of the drawings and the technical information of machinery and equipment, for which such approval is required by the Specifications. One of the three copies so submitted shall be returned, either approved, or supplemented with remarks and amendments, to reach the CONTRACTOR within ... days from the date of receipt by the PURCHASER or within ... days after despatch by the CONTRACTOR, whichever is the sooner, and if this is not done within this time limit

The PURCHASER's Representative whose name, duties and extent of authority are to be made known in advance, shall observe the works' rules prevailing at the CONTRACTOR's and the SUBCONTRACTOR's premises. He shall address his remarks exclusively to the CONTRACTOR's appointed representative(s) whose name(s) shall be made known to the PURCHASER.

the drawings and technical information 



shall be regarded as approved, unless additional time is specifically requested in writing by the PURCHASER and agreed in writing by the CONTRACTOR.

date of receipt of such notice by the PURCHASER of the CONTRACTOR's chosen (selected) suppliers and/or subcontractors or within ... days from despatch on the CONTRACTOR's notice, whichever is the sooner, that it insists on its preference, and in such case the amount of the cost change shall be added to or de-ducted from the contract price. Failing any action by the PURCHASER or

If the drawings and technical information are returned to the CONTRACTOR within the said time limit supplemented with remarks and amendments by the PURCHASER and if the said remarks and amendments are not modifications of such a nature extent as to constitute underor Article 3 hereof, then the CONTRACTOR shall start or continue production on the basis of the corrected or amended drawings and technical information. In case of any dispute concerning the drawings and/or technical information which can not be solved by negotiations the dispute shall be referred to expert¢s assessment in accordance with Art. 15(b) of the CONTRACT. Any delay caused by such dispute shall be Permissible Delay (see Art. 6 (e)).

in casesubject of dissent, the CONTRACTOR's CON-TRACTOR shall, to the guarantee liability under Article 12 hereof, be free to use any of the suppliers and/or subcontractors proposed. It is agreed that all contact with the CONTRACTOR's suppliers concerning supplies intended for the VESSEL under this CONTRACT shall be made through the CONTRACTOR. The above approvals do not diminish the CONTRACTOR's responsibility for the construction of the VESSEL.

There is attached to the Specifications a Makers' List of and major items on whichagree the PURCHASER CONTRACTOR on one or more suppliers and/or subcontractors. The CONTRACTOR shall be free to choose any of the proposed suppliers and/or subcontractors. Should the PURCHASER prefer a particular supplier and/or subcontractor other than the one actually chosen by the CONTRACTOR (whether or not srcinally proposed by the CONTRACTOR) and should the PURCHASER's preference involve a cost change the CONTRACTOR shall quote the amount of such cost change to the PUR-CHASER who shall then have the option to notify the CONTRACTOR within ... days from the 



ARTICLE 3: MODIFICATIONS

(a) PURCHASER’s Modifications

The CONTRACTOR is entitled to make minor changes to the Specifications and drawings, not affecting the VESSEL's performance characteristics if such changes are found necessary to suit the Shipyard's local conditions and facilities, the availability of materials and equipment, the introduction of improved production

The PURCHASER may request the CONTRACTOR in writing to make modifications to the Specifications and the CONTRACTOR will agree to carry out such modifications provided that such modifications or an accumulation of such modifications willjudgement not inadversely the CONTRACTOR's affect the CON-TRACTOR's planning or programme in relation to the CONTRACTOR's other commitments and provided that the CONTRACTOR and the PURCHASER fully agree expressly and in writing within 10 days from the despatch of the CONTRACTOR's notification upon the (a) adjustment of price, (b) adjustment of Delivery Date, (c) adjustment of deadweight and/or grain/bale capacity, (d) adjustment of speed requirements and (e) any other adjustment of the CONTRACT and/or Specifications.

methods or otherwise.

TheSpecifications PURCHASER to will akeep modifications to minimum. The CONTRACTOR has the right to continue production on the basis of the Specifications until agreement has been reached as above stated.

CONTRACT similar measures other bodies and/or as referred to in Article 1,of paragraph (c) ), and such modifications, deletions or additions are compulsory for the VESSEL, the CONTRACTOR will effect them and will state the (a) adjustment of price, (b) adjustment of Delivery Date, (c) adjustment of deadweight and/or grain/bale capacity, (d) adjustment of speed requirements and (e) any other adjustment of the CONTRACT and/or Specifications all as may be appropriate in the circumstances. Any such adjustment of the Delivery Date shall constitute Permissible Delay.

(c) Modifications by Regulatory Bodies and Classification Society In the event that subsequent to the date stated in Article 1 paragraph (c) any modifications, deletions or additions are made to the laws, rules, regulations and enactments applicable to the VESSEL or their interpretation or their application (including withdrawal of provisional approvals of the Classification Society and/or additional requirements of said Society as compared with the basis of this

(b) CONTRACTOR's Modifications The CONTRACTOR may seek the PURCHASER's approval to make changes to the Specifications. These proposed changes will be dealt with in the manner as described in paragraph (a) of this Article.





(d) Payment for adjustments of price

The adjustment of the Delivery Date shall include any adjustment needed by reason of delay caused by the interpretation or consideration of modifications, deletions or additions.

The adjustments of price made under paragraphs (a), (b) and (c) above shall be paid by the PURCHASER in accordance with paragraph (d) of Article 7 in so far as they cause an increase in the price. If the adjustments cause a reduction in price such adjustment shall be credited by the CONTRACTOR to the PURCHASER

The CONTRACTOR may require that the PURCHASER shall first apply for a formal waiver of compliance with such modifications, deletions or additions from the Classification Society Regulatory Bodies authorized to ormake such modifications by whom the modifications, deletions or additions have been promulgated should the PURCHASER consider that the operation of the VESSEL in its intended service would so permit of such waiver. In such agreement the CONTRACTOR will fix a time limit after which, if the waiver has not yet been obtained, the CONTRACTOR will go on with the required modifications, deletions or additions. Any additional cost caused by the application for such waiver whether or not obtained shall be for account of the PURCHASER and the date of delivery of

against the PURCHASER.

by

the

(e) Information When required the CONTRACTOR shall furnish reasonable information relating to the adjustments of price and other effects of modifications referred to in this Article.

the VESSEL be extended by the time necessary asshall a result of the application for waiver. In the event that modifications, deletions or additions referred to in this paragraph (c) above are not compulsory for the VESSEL, such modifications, deletions or additions shall not be effected unless the PURCHASER requests them to be made under the provision of paragraph (a) above.



payments



ARTICLE 4: TRIALS

Bodies, and shall be conducted in a manner and to an extent prescribed in the Specifications and shall prove the VESSEL's proper functioning and fulfilment of the performance requirements for the trials set forth in this CONTRACT and the Specifications.

(a) Notice The CONTRACTOR shall before delivery, with not less than ... days written notice to the PURCHASER notify the time and place for the trial run for the VESSEL and the PURCHASER shall promptly acknowledge receipt of such notice. The PURCHASER shall have the right to have its Representative on board the VESSEL to witness the trial run. Failure in attendance of the Representative at the trial run without any valid reason after due notice to the PURCHASER shall be deemed to be a waiver by the PURCHASER of its right to be present. In such case the PURCHASER shall be obligated to accept the results of the trial run on basis of a certificate of the CONTRACTOR confirmed by the Classification Society stating the results of the trial run.

The methods to be used will be selected by the CONTRACTOR to suit the VESSEL's trial trip program. The CONTRACTOR has the right to subcontract speed and power measurements to an independent model basin or research institute. The CONTRACTOR shall be entitled to conduct preliminary sea trials. The CONTRACTOR shall have the right to repeat any trial whatsoever. All expenses except those of the PURCHASER's Representative and its assistant(s) in connection with the trial run shall be for the account of the CONTRACTOR, including without limitation all necessary crew.

(b) Weather Conditions The trial run shall be carried out under favourable weather conditions. Any delay in delivery caused by delay of the trial run due to unfavourable weather conditions shall be Permissible Delay.

(d) Method of Acceptance or Rejection

The trial run shall be carried out in the presence of representatives from the

Upon completion of the trial run and when the trial results are available, and if the CONTRACTOR considers the results thereof demonstrates that the VESSEL conforms to the CONTRACT, the CON-TRACTOR shall immediately give

Classification Society and/or Regulatory

the PURCHASER a written notice of

(c) Carrying Out





completion stating that the VESSEL is ready for delivery. The PURCHASER shall upon receipt of this notice and the test results notify the CONTRACTOR in writing of its acceptance or rejection of the VESSEL being in conformity with the CONTRACT.

CONTRACTOR may require the PURCHASER to take delivery of the VESSEL provided the CONTRACTOR undertakes for its own account to remedy the deficiency or fulfill the requirement as soon as possible, however latest by the end of the guarantee period.

If the results of the trial run demonstrate that the VESSEL or any part or equipment

If the CONTRACTOR disputes the rejection by the PURCHASER, the case

thereof does not conform to the requirements of the CONTRACT, the CONTRACTOR shall take all necessary steps to rectify such non-conformity. If necessary, the CONTRACTOR shall for its own account carry out a further trial run to ascertain that the VESSEL conforms to the terms of the CONTRACT. Upon demonstration by the CONTRACTOR that the deficiencies have been corrected, a notice thereof stating that the VESSEL is ready for delivery shall be given to the PURCHASER, who shall then upon receipt of such notice together with the new test results notify the CONTRACTOR of its acceptance or rejection.

shall be submitted for finalwith decision by arbritation in accordance Art. 15 hereof.

If the PURCHASER for any reason rejects the VESSEL, the PURCHASER shall in its notice of rejection give particulars of the reason in such detail as can reasonably be expected. The PURCHASER shall be obliged to take delivery of the VESSEL if it is in conformity with the CONTRACT, unless there are any deficiencies or conditions or recommendations imposed by the Classification Society and/or Regulatory Bodies preventing the VESSEL to carry out its intended operation. If the deficiencies or the conditions/recommendations are of minor importance and do not prevent safe

(f) Surplus Consumable Stores

operation 

of

the

VESSEL,

(e) Effect of Acceptance Acceptance of the VESSEL as provided above, shall be final and binding and shall preclude the PURCHASER from refusing formal delivery on basis of any alleged deficiency in any parts of the VESSEL which were tested during the trial run, provided all other procedual requirements for delivery have been met.

Any fuel oil, lubricating oil, grease, fresh water or other consumable stores furnished by the CONTRACTOR for the trial run, remaining on board the VESSEL at the time of delivery shall be purchased by the PURCHASER from the CONTRACTOR at the srcinal purchase price thereof, and payment effected by the PURCHASER on delivery of the VESSEL.

the 

ARTICLE 5:

GUARANTEE FOR SPEED, CARGO CAPACITY AND FUEL CONSUMPTION

Subject to the proviso contained in Article 7 (e) the rights and obligations of the CONTRACTOR and PURCHASER in regard of VESSEL's speed, deadweight, capacity and consumption of fuel of the propulsion plant are delimited as follows.

shall have the right to remedy the deficiency and repeat the trial. Should the actual trial speed of the VESSEL determined or computed as provided in this Article when compared with the trial speed under Article 1, paragraph (a) be greater the PURCHASER shall pay to the CONTRACTOR the following premiums:

(a) Speed For the purpose of determining the VESSEL's actual trial speed, the speed of the VESSEL recorded on the official sea trials under Article 4 shall be adjusted as if the official sea trials had been carried out in the conditions specified in Article 1, paragraph (a), the actual trial speed so computed shall be compared with the trial speed under Article 1, paragraph (a) and if the actual trial speed shall be the lesser, for causes for which the CONTRACTOR is liable, the CONTRACTOR shall pay to the PURCHASER as liquidated damages the

-....for the first two tenths (2/10 ths) of a knot of more speed: ................... nothing -....for each successive whole one tenth (1/10 th) knot thereafter (fractions being disregarded) of more speed: ...................

(b) Deadweight capacity Should the VESSEL's deadweight determined as stated in the Specifications, in salt water of 1,025 specific gravity on

following amounts: -

the design draft of ............... for causes for which the CONTRACTOR is liable, be less than ... percent of the deadweight specified in Article 1 then the CONTRACTOR shall pay to the PURCHASER as liquidated damages an amount equal to ... for each metric ton of deadweight less than ... percent of the specified deadweight disregarding fractions of a metric ton.

for the first two tenths (2/10 ths) of a knot of less speed: ................ nothing for each successive whole one tenth (1/10 th) knot thereafter (fractions being disregarded) of less speed: .....

Should the deficiency in VESSEL's speed for causes for which the CONTRACTOR is liable be more than ... knot(s), then the PURCHASER, as an alternative to receiving the above mentioned liquidated damages, shall have the option to terminate this CONTRACT, with the consequences provided for in Article 11,

Should the VESSEL's deadweight for causes, for which the CONTRACTOR is liable, be less than ... percent of the specified deadweight, the PURCHASER, as an alternative to receiving the above

save and except that the CONTRACTOR 

CARRYING,

mentioned liquidated damages shall have 

the option to terminate this CONTRACT with the consequences provided for in Article 11, save and except that the CONTRACTOR shall have the right to remedy the deficiency and repeat the trial.

mentioned liquidated damages, shall have the option to terminate this CONTRACT with the consequences provided for in Article 11, save and except that the CONTRACTOR shall have the right to remedy the deficiency and repeat the trial.

Should the VESSEL's deadweight be more than ... percent of the specified deadweight, the PURCHASER shall pay to the CONTRACTOR a premium equal to

Should the VESSEL's capacity be in excess of ... percent of the specified capacity, the PURCHASER shall pay to

......... forofeach tonofof deadweight in excess ... metric percent the specified deadweight disregarding fractions of a metric ton.

the each CONTRACTOR to ... for cubic metreaofpremium capacityequal in excess of ... percent of the specified capacity, disregarding fractions of a cubic metre.

(c) Grain/bale Capacity

(d) Fuel Consumption

The net capacity of the cargo holds, viz: ... .................................................................... .................................................................... .................................................................... grain/bale/ 100 percent full shall be ........... cubic metres.

For the main propulsion plant test bed trials shall be carried out at the manufacturers site in accordance with the Specifications. During the test bed trials the specific fuel consumption shall be ascertained and corrected to the design parameters.

Should the VESSEL's capacity, for causes for which the CONTRACTOR is liable, be less than ... percent of the specified capacity, the CONTRACTOR shall pay to the PURCHASER as liquidated damages an amount equal to .................. (the CONTRACT price as specified in Article 7, paragraph (a) divided by the specified capacity) for each cubic metre of capacity less than ... percent of the specified capacity, disregarding fractions of a cubic metre.

The fuel consumption of the main propulsion plant during the test bed trials shall not exceed ... gram per shaft KW per hour using oil having a lower calorific value of .................... kcalories per kg. In case the actual lower calorific value of the fuel used differs from the figures mentioned in this paragraph, the fuel consumption will be corrected accordingly.

Should the VESSEL's capacity, for causes for which the CONTRACTOR is liable, be less than ... percent of the specified capacity the PURCHASER, as an

Should the corrected fuel consumption per gram per shaft KW per hour for causes for which the CONTRACTOR is liable, be in excess of ... percent of the specified fuel consumption, the CONTRACTOR shall pay to the PURCHASER, as liquidated

alternative

damages, an amount of .................. for



to

receiving

the

above 

each gram per shaft KW metric per hour in excess of ... percent of the specified fuel consumption disregarding fractions of one gram. Should the corrected fuel consumption, for causes for which the CONTRACTOR is liable, be in excess of .... percent of the specified fuel consumption, the PURCHASER, as an alternative to receiving the above damages, shall havementioned the option liquidated to refuse the main propulsion machinery in which event the CONTRACTOR shall be allowed reasonable time to replace the same, save and except that the CONTRACTOR shall have the right to remedy the deficiency and repeat the trial.





ARTICLE 6: DELIVERY OF THE VESSEL

(a) Time and Place of Delivery

All Certificates including the Builder¢s Certificate required to be furnished upon delivery of the VESSEL pursuant to this CONTRACT and the Specifications. It is agreed that if the Classification Certificate and / or other Certificates are not available at the time of delivery of the VESSEL,

The VESSEL shall be delivered to the PURCHASER at the Shipyard or other agreed place on or before .................(the "Delivery Date") ....................................... The Delivery Date as set out above shall be subjectofto all extension by the Delays cumulative amount Permissible as provided for in this CONTRACT.

provisional CertificatesThe shallCONTRACTOR be accepted by the PURCHASER. shall provide the PURCHASER with the formal Certificates as promptly as possible after such formal Certificates have been issued.

The PURCHASER shall take possession of the VESSEL immediately upon delivery and acceptance thereof and shall with reasonable despatch remove her from the Shipyard. The VESSEL shall be delivered to the PURCHASER free from all liens and encumbrances.

Declaration of Warranty of the CONTRACTOR that the VESSEL is delivered to the PURCHASER free and clear of any and all liens and other encumbrances upon the VESSEL and the PURCHASER's title hereto, and in particular, that the VESSEL is absolutely free of the burdens, in the nature of imposts, taxes or charges imposed by the

(b) Delivery Documentation Upon delivery and acceptance of the VESSEL, CONTRACTOR deliver to the the PURCHASER the shall following documents, which shall accompany the Protocol of Delivery and Acceptance:

city,well state of thearising part of from delivery, as asorofcountry all liabilities the construction or operation of the VESSEL or trial runs or otherwise prior to delivery and acceptance.

Protocol of Trials of the VESSEL made pursuant to the Specifications.

Drawings and Plans pertaining to the VESSEL as stipulated in the Specifications.

Protocol of Inventory of the equipment of the VESSEL, including spare parts and the like, all as specified in the Specifications.

Commercial Invoice. A protocol of delivery and acceptance will be signed by the CONTRACTOR and the PURCHASER.

Protocol of Stores of consumable nature.





(c) Liquidated Damages and Premiums

other hostilities or preparations therefore, civil commotions, riots or insurrections; blockades; embargoes, export or import restrictions; epidemics; strikes, lockouts or other labour disturbances or difficulties whatsoever; earthquakes; landslides; floods; exceptional weather conditions not included in normal planning; prolonged failure of electric current; damage by fire, lightning or explosion; accidental damage

Should the VESSEL, for causes for which the CONTRACTOR is liable not be delivered on the Delivery Date, as extended for Permissible Delays under the terms of this CONTRACT, the CONTRACTOR shall subject to the proviso contained in Article 7 (e) pay to the PURCHASER as liquidated damages an amount ........................ working day of of delay, beginningfor on each the ... day of delay, up to maximum of ... days.

including damage to the VESSEL and time taken to repair such damage; shortage of materials and equipment or inability to obtain delivery thereof; rejection of or defects in materials and equipment which could not have been detected; defects in castings or forgings; or any other delays whatsoever provided in any such case that the delay could not have been avoided by reasonable efforts on the part of the CONTRACTOR, or should the construction or delivery of the VESSEL be delayed owing to causes of any of the foregoing kinds affecting the CONTRACTOR¢s other commitments, then and in any such case the number of

Should the delay in delivery for causes for which the CONTRACTOR is liable exceed 360 days from the date set forth under paragraph (a) above as extended for permissible extensions under the terms of this CONTRACT, the PURCHASER, as an alternative to receiving the above mentioned liquidated damages, shall have the option to terminate this CONTRACT with the consequences provided for in Article 11. Should the VESSEL completed the Delivery Date beset forth before under paragraph (a) , the PURCHASER shall subject to the proviso contained in Article 7 (e) pay to the CONTRACTOR a premium equal to ............................ for each working day of earlier delivery, beginning on the ... day after completion.

days of delay caused shall be Permissible Delaysoand the VESSEL¢s Delivery Date shall be postponed by the cumulative amount of such Permissible Delays. Within ... days after the CONTRACTOR becoming aware of the extent of an event of force majeure the CONTRACTOR shall notify the PURCHASER in writing thereof indicating the extent of the delay so caused.

(d) Force Majeure Should the construction or delivery of the VESSEL be delayed or any work required of the CONTRACTOR hereunder be prevented or hindered by events such as, but not limited to: Acts of God; war or 



(e) Permissible Delay "Permissible Delay" means any delay on account of causes specified in paragraph (d) of this Article or any other delay by reason of events which permit adjustment or postponement of the Delivery Date under the terms of the CONTRACT.





ARTICLE 7: PRICE

(a) Contract Price

(d) Payment for Modifications

The CONTRACT price is ......................... (in words: ...............................................)

The sums due for modifications under Article 3 of this CONTRACT shall be paid as follows:

(b) Instalments

(I) 50 % on the date of agreement for modifications under Paragraph (a) and (b) of Article 3 or for modifications under paragraph (c) of Article 3 when the Statement of the adjustment of price is made by the CONTRACTOR as the case may be.

Payment of the CONTRACT price shall be made by the PURCHASER to the CONTRACTOR by instalments as follows: ................................................................. Bank guarantees for the different instalments have to be provided by the PURCHASER before the effective date of the CONTRACT as provided for in Article 16 to the satisfaction of the CONTRACTOR.

(II) 50 %on the date of delivery of the VESSEL as part of the delivery instalment.

(c) Payment Procedures

(e) Payment for liquidated Damages and Premiums

Except for the first instalment the

Any amounts for liquidated damages or

CONTRACTOR shall notify the PURCHASER at least ten (10) days in advance of the estimated dates of the instalment payments falling due.

any premiums under Article 5 and 6 shall be calculated and determined on delivery of the VESSEL and the balance (of one over the other) shall be paid to the party entitled thereto on the VESSEL's delivery, provided that, if the balance exceeds 10 percent of the CONTRACT price in paragraph (a) of this Article then the payment shall be equal to 10 percent of this said price.

All payments to the CONTRACTOR are to be made in ..................................... at a bank to be designated by the CONTRACTOR without any deduction whatsoever on the dates on which the payments are due.

The liquidated damages provided for in this agreement shall be in full and final settlement and the PURCHASER hall not be entitled to demand additional

Expenses for remitting payments and any other expenses connected with such payments shall be for the account of the PURCHASER.

indemnification. 



(f) Prompt Payment The PURCHASER shall not delay any payment in case of any disagreement as to the amount of the above liquidated damages or premiums or in the event of other exceptions or claims the PURCHASER may have asserted or may intend to assert against the CONTRACTOR, whether in connection with this CONTRACT or otherwise without prejudice to the PURCHASER's right to apply subsequently to Arbitration. The right of retention or set-off with counterclaims of the PURCHASER is excluded.





ARTICLE 8: PROPERTY

(a) General Plans, Specifications and Working Drawings The CONTRACTOR retains all rights to the Specifications, plans and working drawings, technical descriptions, calculations, test results and other data

On delivery of the VESSEL to the PURCHASER every responsibility for the safety and generally for the condition of the VESSEL is transferred to the

information documentsofconcerning the design and and construction the VESSEL and the PURCHASER undertakes therefore not to bring them to the knowledge of third parties, without the prior written consent of the CONTRACTOR except if and to the extent necessary in the normal operation or repair of the VESSEL.

PURCHASER, onandthe thereafter responsibilities part of theall CONTRACTOR shall cease with the exception of the guarantee obligations provided for in Article 12 hereof.

(b) Property In the VESSEL During construction the VESSEL shall be the CONTRACTOR's property and the CONTRACTOR undertakes not to dispose of the VESSEL and not to allow any mortgage or lien being registered on the VESSEL except with the PURCHASER's prior written consent.





ARTICLE 9: INSURANCE

The VESSEL and/or such parts as shall be constructed and all materials, engines, machinery, outfit and equipment pertaining to this CONTRACT and within the premises of the Shipyard shall immediately be marked with VESSEL's yardnumber and shall until delivery of the VESSEL be insured by the CONTRACTOR at CONTRACTOR's expense - policy being in the name of the CONTRACTOR - against all risks customarily insured against in ....... shipbuilding industry including trials with the exception of war risks and in accordance with and subject to the terms of the usual construction policy for a total of not less than the amount for the time being paid by the PURCHASER to the CONTRACTOR for the VESSEL. If considered necessary by the CONTRACTOR or if required by the PURCHASER war risks insurance for not less than the CONTRACT price to be

account of any such damage or any repair thereof be entitled to object to the VESSEL or to make any claim for alleged consequential loss or depreciation. Underwriters are entitled to settle claims concerning repairable damage to the VESSEL directly with the CONTRACTOR, and make all payments on these claims directly to the CONTRACTOR. The CONTRACTOR shall be allowed additional time equivalent to any delay in delivery caused by any such damage or any repair thereof.

effected by the CONTRACTOR at PURCHASER's account up to the date of delivery to the extent that such insurance is obtainable on the ...... insurance market.

loss any insurance monies shall be paid to the PURCHASER for reimbursement of the amount paid by the PURCHASER to the CONTRACTOR hereunder; any balance shall belong to the CONTRACTOR. Under no circumstances shall the CONTRACTOR be liable to replace the VESSEL.

Should the VESSEL from any cause become or be deemed to be at any time a constructive, arranged or compromised total loss under the insurance policy, this CONTRACT shall if not otherwise agreed between the parties thereupon absolutely cease and terminate without any liability whatsoever on the part of the CONTRACTOR. In the event of such total

In the event of the VESSEL and/or such parts materials etc. as aforesaid sustaining damage, including war damage, before delivery of the VESSEL then any monies received in respect of any insurance effected under this Article shall be applied by the CONTRACTOR in making good such damages with all due despatch during ordinary working hours in a reasonable and workmanlike manner

The CONTRACTOR's liability to the PURCHASER in respect of damage including war damage - or in respect of the constructive, arranged or compromised total loss of the VESSEL, shall not in any event extend further or otherwise than in

and the PURCHASER shall not on 

this Article provided. 

ARTICLE 10: DEFAULT BY THE PURCHASER

Should the PURCHASER be in default in payment of any CONTRACT instalment and/or other amounts due under this CONTRACT, then the PURCHASER shall pay to the CONTRACTOR - as from the due date - interest thereon at the rate of ........................ percent per annum over ... .

In the event of termination of the CONTRACT as above provided, the CONTRACTOR is herewith irrevocably authorized by the PURCHASER to sell the VESSEL before or after having completed her without prejudice to any other CONTRACTOR's rights.

The CONTRACTOR shall be entitled to one day¢s postponement of the Delivery Date of the VESSEL for each day of delay in excess of two days in the payment of the aforesaid sums and if the delay exceeds 15 days as from the due date the CONTRACTOR shall have the option to suspend the CON-TRACTOR's obligations under this CONTRACT until payment of such sums and interest thereon has been received by the CONTRACTOR.

Should PURCHASER fail to take delivery the of the completed VESSEL in accordance with the terms of this CONTRACT the amounts due on or related to delivery by the PURCHASER to the CONTRACTOR shall be regarded as having fallen due upon receipt of written notice. The CONTRACTOR shall inform the PURCHASER about the dates on which the PURCHASER has to deliver its supplies (as specified in the Specifications) at the Shipyard. Should the CONTRACTOR fail to deliver its supplies within the designated delivery time, the

If the aforesaid delay exceeds 30 calendar days from the due date, the CONTRACTOR, even if it has elected to suspend theterminate work as the aforesaid, may have the right to CONTRACT by giving notice in writing, which may be by telefax if confirmed by letter, to the PURCHASER about such termination. In this event the CONTRACTOR shall be entitled to recover damages from the PURCHASER in respect of any loss that the CONTRACTOR has suffered by reason of the PURCHASER¢s default.



incurred delay shall be Permissible Delay.



ARTICLE 11: DEFAULT BY THE CONTRACTOR

If in accordance with any of the provisions of Article 5 or 6 the PURCHASER shall, as an alternative to receiving the liquidated damages therein referred to, exercise the option of the PURCHASER to terminate this CONTRACT, then, provided that the right of the PURCHASER to exercise this option is not disputed by the

............................ as from the date when such monies were paid by the PURCHASER to the CONTRACTOR up to the date of the repayment thereof. Upon the termination of the CONTRACT by the PURCHASER as aforesaid the CONTRACTOR shall irrevocably be authorized by the PURCHASER to sell the

CONTRACTOR subjecthereof, to arbitration under Article and 15 the CONTRACTOR shall be liable to repay to the PURCHASER the amount of all monies paid by the PURCHASER for or on account of the CONTRACT price of the VESSEL together with interest at the rate of ....................... percent per annum over.

VESSEL or after completion and to keep the before proceeds.





ARTICLE 12: GUARANTEE

(a) Extent of Guarantee

Replacements and repairs pursuant to the CONTRACTOR's guarantee obligations shall be subject to guarantee in accordance with this article, provided that the guarantee period in regard to such replacements and repairs shall start at the date of completion thereof and provided that the total guarantee period shall never

On delivery of the VESSEL the CONTRACTOR shall be free of all responsibility or liability whatsoever except for the guarantee contained in this Article. The CONTRACTOR shall remedy at (one of) its yard(s) and in theornormal working hours, by repairing if necessary replacing at its own cost any defects notified in writing by the PURCHASER on the VESSEL's delivery due to bad workmanship and/or use of defective materials or defects not discoverable on delivery which become apparent during the period of ............. days from the date of delivery of the VESSEL provided the defect is notified in writing within 30 days from its discovery.

exceed a period of two years after delivery of the VESSEL. If the replacements or repairs under this Article cannot be conveniently made at (one of) the CONTRACTOR¢s yard(s), the PURCHASER may have carried out elsewhere such repairs and/or replacements; in such a case the CONTRACTOR is discharged from this guarantee and shall reimburse the PURCHASER the documented expenses incurred by the PURCHASER, but such a reimbursement shall not exceed the estimated costs of carrying out the guarantee work at the CONTRACTOR¢s

The guarantee shall apply only to the work of the CONTRACTOR and of its subcontractors and/or suppliers. The CONTRACTOR's liability obligations shall be limited to the above mentioned as to ex-tent and duration and the CONTRACTOR and/or its subcontractors and suppliers shall have no further liability whatsoever for any direct or indirect loss, damages or expense in any way deriving from or connected with the above defects and for defects due to normal wear and tear or overloading or due to corrosion of the materials or due to accidents, fire, improper loading or stowage of the VESSEL, mismanagement or negligence in the use and maintenance of the VESSEL.

yard(s). In any event the VESSEL shall be taken at PURCHASER's cost and responsibility to the place elected by the PURCHASER ready in all respects for the guarantee work to be commenced. In the event that the guarantee period provided by manufacturers or suppliers of various components of machinery, materials, equipment, appurtenances and outfit furnished to the CONTRACTOR and embodied in the VESSEL exceeds the aforesaid guarantee period, such extended guarantee rights are to be assigned and made available to the





PURCHASER by the CONTRACTOR to the extent possible.

The PURCHASER shall ensure the said Engineers a status on board not inferior to that due to the Chief Engineer and pay the CONTRACTOR a remuneration to be agreed upon.

The CONTRACTOR, at its own cost, is to have the right to investigate the validity of the PURCHASER's claim either by the attendance aboard the VESSEL (without interruption to the operation of the VESSEL) of an accredited representative or, in the event it is practicable to do so

The presence on board of the Guarantee Engineers shall in no way affect CONTRACTOR's and PURCHASER's responsibility as provided for in this

after suitable is made, removal fromreplacement the VESSEL andby the the transportation to the CONTRACTOR¢s yard(s) of the defective part.

CONTRACT andany thefaults CONTRACTOR not be liable for or omissionsshall on the part of the Guarantee Engineer.

This guarantee shall not apply to items supplied by the PURCHASER. (b) Guarantee Engineer During any time of the guarantee period the CONTRACTOR shall have the option to place on board one or two Guarantee Engineers who shall act as CONTRACTOR's observers and to whom every assistance shall be granted for the fulfilment of their then tasks. Should this option be exercised such Guarantee Engineers shall not be discharged without the CONTRACTOR's approval.





ARTICLE 13: CONTRACT EXPENSES

All taxes, duties, stamps and fees levied by the Authorities in ................. and connected to this CONTRACT are to be borne by the CONTRACTOR.



Any taxes, duties, stamps and fees outside are to be borne by the PURCHASER.



ARTICLE 14: PATENTS

The CONTRACTOR shall indemnify the PURCHASER against any infringement of patent rights by or in connection with the construction at the Shipyard, of the VESSEL, but no such liability shall lie with the CONTRACTOR with regard to components and/or equipment and/or design supplied by the PURCHASER.



Nothing contained herein shall be construed as transferring any patent or trademark rights or copyright in equipment covered by the CONTRACT, and all such rights including the design of the VESSEL are hereby expressly reserved to the true and lawful owners thereof.



ARTICLE 15:

INTERPRETATION, REFERENCE TO EXPERT AND ARBITRATION

(a) Interpretation

hereto and the third arbitrator by the two thus chosen.

This CONTRACT supersedes all prior negotiations, representations, undertakings and agreements of any subject matter to this CONTRACT.

The arbitration shall be conducted at .................................................................... under the laws of ....................................... The party desiring such arbitration shall

This CONTRACT and all other agreements relating thereto shall be construed and interpreted under the laws of ................................................................

serve upon the other party written notice of its desire, specifying the question(s) to be arbitrated and naming the arbitrator chosen by it.

(b) Reference to expert¢s assessment

The party so notified shall in turn notify in the same way the name of its arbitrator and its own question(s), if any.

Save as provided in Article 1 (e) should any dispute arise between the parties in regard to the construction of the VESSEL, engines materials or workmanship it shall forthwith be referred to an expert nominated by agreement between the parties hereto or failing such agreement by the ......................................................

In the event that one of the parties fails to choose its arbitrator after having been duly notified in writing by the other party to do so, within twenty (20) days after such notice, or in the event that two arbitrators chosen by both parties within a period of 20 days after appointment of the second

and decision be final and binding uponhis both parties shall hereto.

arbitrator fail to select third arbitrator then respectively each the party or the other party shall have the right to request the President of the ......................................... .................................................................... to nominate the arbitrators for the open place(s).

(c) Arbitration In the event of any dispute or difference between the Parties hereto as to any matter or thing arising out of or relating to this CONTRACT or its termination or any stipulation herein not already covered in paragraph b) above which cannot be settled by the parties themselves, the parties shall submit the matter in dispute to arbitration by three arbitrators, one of the arbitrators to be chosen by each party

The decision of the arbitrators shall be final, conclusive and binding upon both parties thereto. The Arbitrators so appointed shall determine which party, or the proper proportion which each party shall assume of the expenses of such arbitration and the arbitration expenses so allocated shall be





paid directly by the party or parties by which such expenses are directed to be paid.





ARTICLE 16: CONDITIONS FOR THE CONTRACT TO BECOME EFFECTIVE

This CONTRACT shall become effective the day after all the following conditions have been fulfilled:

Should any of the above conditions not be fulfilled within .................... days from the date of signature of this CONTRACT, this CONTRACT shall not become effective and shall be regarded as never entered into; in such case no obligations

The PURCHASER and the CONTRACTOR shall notify each other in writing, which may be by telefax if confirmed by letter, of the fulfilment of the above conditions.



whatsoever shall remain between the parties.



ARTICLE 17: LEGAL DOMICILE

For all the purposes of this CONTRACT the PURCHASER elects its legal domicile at its registered office in ..........................



and the CONTRACTOR at its registered office in ...................................................... ....................................................................



ARTICLE 18: ASSIGNMENT

Neither party shall be entitled to transfer its rights unless prior written approval has been obtained from the other party, which shall not be unreasonably withheld. Both parties shall have the right to study all documents relevant to such transfer and to renegotiate such terms and conditions as it requires.



All costs of any kind whatsoever, including legal and other costs in relation to such assignment shall be borne and paid for by the new party to the CONTRACT. The srcinal party shall guarantee performance and shall jointly and severally with the new party be liable under the terms of the CONTRACT.



ARTICLE 19: LIMITATION OF LIABILITY

The liability of the CONTRACTOR shall be limited to the remedies provided for the PURCHASER in this CONTRACT and there shall be no further liability whatsoever for any direct or indirect losses, damages or expenses deriving from the obligations of the CONTRACTOR under this CONTRACT.





ARTICLE 20: ADDRESSES FOR CORRESPONDENCE

(a) For practical purposes without it being a legal requirement the CONTRACTOR shall send all letters and documents for the PURCHASER in connection with and required under this CONTRACT to the following addresses:

(I) for all technical matters: address: .............................................................................................................................. att........................................................................................................................................ telephone:........................................................................................................................... telefax: ................................................................................................................................ eMail: ..................................................................................................................................

(II) for all legal and financial matters: address: .............................................................................................................................. att........................................................................................................................................ telephone:........................................................................................................................... telefax: ................................................................................................................................ eMail: ..................................................................................................................................





(b) For practical purposes without it being a legal requirement the PURCHASER shall send all letters and documents for the CONTRACTOR in connection with and required under this CONTRACT to the following address:

(I) for all technical matters: address: .............................................................................................................................. att........................................................................................................................................ telephone:........................................................................................................................... telefax: ................................................................................................................................ eMail: ..................................................................................................................................

(II) for all legal and financial matters: address: .............................................................................................................................. att........................................................................................................................................ telephone:........................................................................................................................... telefax: ................................................................................................................................ eMail: ..................................................................................................................................

In witness whereof the parties have executed this CONTRACT by their duly authorised representatives as follows.



